Home

Technical Specifications with annexes

1. Engine in CW _ Temp CC Engine Oil Pressure Bar Vessel Speed Knots Engine Speed rpm Fuel Consumption litres mintue Time Finish Time Start Others Others At Minimum Cinsine Sneed Not less 15 mintues 50 of Rated Power Not less 15 mintues 60 of Rated Power Not less 15 mintues 70 of Rated Power Not less 15 mintues 80 of Rated Power Not less 15 mintues 90 of Rated Power Not less 15 mintues 100 of Rated Power Endurance Witness by Not less 120 mintues or 120 min 3 to be discussed with Immigration Dept MD Representative Shipyard Representative Part VII Annex 13 Endurance and Performance Test Supply of Two Units of Speed boats for Marine Department Tender Ref Marine Department Shipbuilding Tender No 3 2015 Annez 14 As fitted Drawings and Machinery Eguipment documents and information literature to be delivered to the Government after Delivery Acceptance 1 As Fitted Drawings 1 1 After the Vessel is delivered to the Government the Contractor shall deliver to the Government within two 2 calendar months four 4 hard copies and two 2 soft copies of the following plans and drawings that contain the technical information of the Vessel and its machinery and equipment as they are when the Vessel is on the day accepted by the MD These are termed the final version of the As Fitte
2. Country Currency City Virgin Islands Charlotte Amalie USD 478 All rates to be Others USD 478 reduced by 10 Virginia for stay in any one Richmond USD 227 city Others USD 227 Washington DC USD 355 Washington State Olympia USD 201 Fort Lewis USD 217 Seattle USD 307 Others USD 201 West Virginia Charleston USD 201 Others USD 201 Wisconsin Madison USD 199 Milwaukee USD 214 Others USD 199 Wyoming Cheyenne USD 165 Others USD 165 Uruguay Montevideo UYU 6 242 Colonia UYU 6 564 Punta del Este UYU 8 743 Others UYU 6 242 Uzbekistan Tashkent UZS 662 625 Others UZS 337 250 Vanuatu Port Vila VUV 35 799 Santos VUV 26 555 43 Amendment No 8 43 2015 Tender Ref Marine Department Shipbuilding Tender No 3 2015 Annex 4 10 First 28 nights Thereafter Country Currency City Tanna Island VUV 35 013 Others VUV 3 246 All rates to be Venezuela reduced by 10 Caracas VEF 3 623 for stay in any one Barquisimeto VEF 3 541 city Maracaibo VEF 3 548 Porlamar VEF 3 447 Puerto La Cruz VEF 3 050 Puerto Ordaz VEF 3 144 Punto Fijo VEF 2 974 San Cristobal VEF 3 440 Valencia VEF 3 182 Others VEF 3 050 Vietnam Hanoi VND 5 899 452 Dalat VND 5 177 936 Danang VND 5 114 273 Ho Chi Minh City VND 6 493 641 Others VND 4 392 757 Virgin Islands British Virgin Islands British USD 258 Wallis and Futuna Wallis and Futuna XPF 12 970 Yemen Sanaa YER 97 853 Aden YER 47 744 Others YER 37 206 Zambia Lusa
3. material All materials used shall be resistant to deterioration by the fuel for which the system is designed and to other liquids or compounds with which the material can come in contact as installed under normal operating conditions e g grease lubricating oil bilge solvents and sea water Internal surfaces of the diesel tank shall be left unpainted and the diesel tank internal shall be cleaned thoroughly to the satisfaction of MD Provisions to the Diesel Tanks 25 3 6 1 A tank content gauge and low level alarm shall be fitted on the control console for each tank A sounding rod calibrated in litres shall be supplied for each tank 25 3 6 2 Marine grade stainless steel 316 with increased resistance to corrosion shall be used The thickness shall sustain the loads due to the mass of the full tank with due consideration given to upward and downward acceleration due to the vessel s movements at maximum speed in the sea without damaging the integrity of the tanks 25 3 6 3 The fuel tank shall have all fittings and openings on top except metallic fill and ventilation pipes which may be connected to the sides or ends of metal petrol fuel tanks provided that they are welded to the tank and reach above the top of the tank 25 3 6 4 Rigid fuel suction tubes and fill pipes which extend near the tank bottom shall have sufficient clearance to prevent contact with the bottom during normal operation of the craft 25 3 6 5 An inspection manhole air
4. shall be submitted for MD approval before the Completion Date stipulated in Annex 5 to this part Detailed wiring diagrams of the complete supply and distribution network including wire size insulation and sheathing shall be submitted for MD approval before the Completion Date stipulated in Annex 5 to this part All Equipment installed shall be provided with manuals for operation and maintenance The standard of installation shall enhance the Equipment s safety features of not presenting any hazards to the operator e g all metal panels exposed to the operator shall be grounded properly Warnings of any potential hazards shall be displayed in both English and Chinese or with universally recognised labels Two groups of 12 24 volt maintenance free batteries one for outboard engine starting and the other for shipboard services shall be provided These two groups of batteries shall be connected to two independent DC circuits with a crossover network They shall be interchangeable to back up each other and be capable of being charged by the engine driven alternator individually The capacities of these batteries shall be sufficient to provide at least 6 consecutive starts of the engines from cold without recharging and maintain an uninterrupted power supply to the shipboard services e g navigational lights general lights alarm etc The engine driven alternators shall be able to charge the batteries and to provide 12 24V DC power to the
5. 10 6 3 Hand holds and grab rails 10 6 4 Marine heavy duty straightline type wipers with water spray shall be provided for all front windows 11 Hand Holds and Grab Rails 11 1 11 2 Sufficient internal and external hand holds and guard rails shall be fitted on the Vessel Guard rails on the main deck outside the housing must be non reflective and fabricated to suit for a marine environment i e aluminium alloy high grade stainless steel SS 316 or other appropriate non corroding material The design and arrangement of all onboard fittings including guard railings their position fitting arrangement etc shall be made acceptable to and approved by MD before fitting 12 Consoles 12 1 12 2 12 3 12 4 12 5 The layout of control console shall be submitted for MD approval before the Completion Date stipulated in Annex 5 to this part Console 12 2 1 The coxswain controls and displays shall easily be reached by a normal Asian stature in his her fixed position standing without needing to extend arms and field of view of coxswain 12 2 2 The console shall be designed such that from normal working position the total required left to right viewing angle shall not exceed 190 degrees and preferably whenever possible through appropriate control display layout 12 2 3 The controls or displays of following equipments shall be installed in the Console and located in front of coxswain and commander in natural positions with the highest
6. 7 4 7 Procedures for non conformance reporting and rectification of defects 7 4 8 Design and manufacturing drawing control and procedures for revisions updates and reissue of drawings 7 3 The hull of the proposed Vessel shall be constructed so that it will be capable of sustaining frequent impacts during boarding and intercepting operations in sea conditions specified in paragraph 1 3 of Chapter 2 to these Technical Specifications 7 6 The openings in hull and deck such as portlights doors hatch covers etc shall comply with international standards or rules acceptable to MD 7 7 Cathodic protection system shall be provided to protect the hull to suit for a minimum one year life with suitable numbers of anodes secured to the hull below the lightship waterline at the appropriate location 7 7 1 The actual numbers size and positions of the anodes and method of the securing shall strictly follow the instruction required by the proposed anode manufacturer 8 Painting 8 1 Paints shall be of a fire retarding marine quality readily available in HKSAR and with manufacturer s authorised local technical support and applied in accordance with manufacturer s specification A painting report shall be submitted to MD upon completion of work 8 2 Volatile Organic Compounds VOC content limits of the paints shall comply with the Controls and Requirements of the VOC Regulation VOC content limits for regulated vessel paints and regulated pleasure
7. Conakry GNF 2 295 483 Others GNF 737 082 Guinea Bissau Bissau XOF 123 822 Others XOF 60 870 Guyana Georgetown GYD 42 001 Others GYD 42 001 Haiti Port au Prince HTG 11 811 Cap Haitien HTG 10 701 Jacmel HTG 7 681 Montrouis HTG 10 612 14 Amendment No 8 14 2015 Tender Ref Marine Department Shipbuilding Tender No 3 2015 Annex 4 10 First 28 nights Thereafter Country Currency City Petionville HTG 11 811 Others HTG 7 992 All rates to be Holy See reduced by 10 Holy See EUR 457 for stay in any one Honduras city Tegucigalpa HNL 5 551 Bay Islands HNL 5 320 La Ceiba HNL 3 764 San Pedro Sula HNL 5 509 Tela HNL 3 890 Others HNL 3 049 Hungary Budapest HUF 62 326 Papa HUF 29 069 Others HUF 29 069 Iceland Reykjavik ISK 40 945 Akureyri ISK 31 981 Others ISK 28 952 India New Delhi INR 24 716 Agra INR 12 482 Bangalore INR 29 288 Chennai INR 25 396 Goa INR 13 470 Hyderabad INR 21 318 Kolkata INR 25 705 Mumbai INR 31 822 Pune INR 21 318 Trivandrum INR 14 706 Others INR 17 981 Indonesia Jakarta IDR 4 403 911 Bali IDR 4 781 042 15 Amendment No 8 15 2015 Tender Ref Marine Department Shipbuilding Tender No 3 2015 Annez 4 10 First 28 nights Thereafter Country Currency City Banda Aceh IDR 1 788 329 Bandung IDR 3 953 788 All rates to be Batam IDR 1 581 515 reduced by 10 Denpasar IDR 4 781 042 for stay in any one Jayapura IDR 2 031 639 city Medan IDR 1 776 163 Surabaya ID
8. Contract The non compliance with any specifications set out in these Technical Specifications shall the same consequences as specified in the Contract 1 5 The Vessel shall be Ready for Use before the Delivery Date and delivered by the Delivery Date as per the schedule stipulated on Schedule 2 Delivery Schedule 1 6 The Government New Construction Section GNC of MD is the section responsible for the procurement of the Vessel for the Government of the Hong Kong Special Administrative Region HKSAR of the People s Republic of China hereinafter referred to as Government Electrical and Mechanical Services Department EMSD will oversee the Communication and Electronic Navigation Equipment ENE technical acceptance 2 Design and Construction Responsibility 2 1 It is the SOLE responsibility of the Contractor and the Government relies on the professional judgment and skill of the Contractor to supply a Vessel which is safe fit and suitable for the operation of the user department and which meets all the Essential Requirements and which meets all the Essential Requirements and the specifications in these TS not labeled as E which include without limitation requirements for safety hull form design features structure method and materials for construction and fitting out stability sub division and operational efficiency 2 2 Notwithstanding the submission of the preliminary plans and drawings by the Contractor then as part of its t
9. Emergency Steering Test Conditions at Astern Running Test Emergency Steering Test 1 Person Onboard 6 Persons 2 Deadweight 75 kg x 6 500 kg 3 Fuel Petrol 40 50 of Fuel Tank 4 Other Equipment 100 kg 5 Sea Conditions wind speed below 11 knots 6 Others All the machinery and equipment as required in the Technical Specifications shall be fully installed onboard Part VII Technical Specifications Annex 8 Sea Trial Conditions Page 2 of 2 Tender Ref Marine Department Shipbuilding Tender No 3 2015 Part VII Annex 9 Delivery Acceptance Procedures 1 Intr ion Delivery Acceptance Procedures DAP provide formal procedures for the acceptance of new government vessel s delivered to HKSARG The term Delivery is defined in the General Conditions of the Contract DAP is regarded as the procedures which would lead to the physical possession of the vessel s by HKSARG as represented by MD Delivery is completed when the DM as represented by AD GF has issued the Certificate of Acceptance DAP should follow the terms and conditions stipulated in the General Conditions of the Contract If there is any discrepancy between DAP and the terms of the General Conditions the General Conditions prevail Any documents signed by MD officer during the process are solely a record of facts The Payment Recommendation Procedures PRP must be followed in processing payment 2 Pr r When SS GNC has received from the Contra
10. If the Contractor appoints a GRSS to perform the Warranty Services the Contractor shall ensure and procure that the GRSS appointed it will perform the Warranty Services and Guarantee Slipping in full compliance with the requirements of the Contract including those as set out in this Annex 1 as if references to the Contractor mean such GRSS The purposes of requiring GRSS for providing the Warranty Services is to facilitate rectification of defects without causing inconvenience to the Vessel s operation As such if the GRSS is a third party but not the Contractor the Contractor shall give and shall be deemed to have given full authorization to that GRSS in the HKSAR for making decision in relation to all matters arising out of any warranty claims submitted by the Government but the Government reserves all rights and claims against the Contractor in the event that any warranty claim has not been handled in accordance with the terms of the Contract For those Equipment in respect of which the manufacturer supplier does not offer free one year warranty on such equipment the Contractor shall ensure that the GRSS will provide the Warranty Services throughout the Warranty Period at its own cost For other loose equipment and installation such as life saving and fire fighting equipment etc which are required to be serviced inspected or renewed annually the GRSS shall provide the servicing inspection and renewal as per the manufacturer s requiremen
11. Navigational and Signalling Equipment Search Lights Life saving Appliances and Fire fighting Equipment Markings and Colour Scheme Tally Plates Requirements for Electronic and Navigation Equipment Services Support Information to be Provided Prior to and at Delivery Acceptance Training on Handling and Maintenance of Vessel Part VII Technical Specification Supply of Two Units of Speed Boats for Marine Department Page 2 of 37 Tender Ref Marine Department Shipbuilding Tender No 3 2015 Annez 1 Annez 2 Annez 3 Annex 4 Annex 5 Annex 6 Annex 7 Annex 8 Annex 9 Annex 10 Annex 11 Annex 12 Annex 13 Annex 14 Warranty Services and Guarantee Slipping Stability Requirements Guidance General Arrangement Plan Implementation Table Timetable for Drawings Submission Timetable for Main Inspection Items List of Government Dockyard Contractors Item III Hull Deck amp Tailshaft Group I Conditions for Official Sea Trial Delivery Acceptance Procedure Definitions of Wave and Sea Markings and Colour Scheme Government Subsistence Allowance Rate Results for Endurance and Performance Tests As fitted Drawings and Machinery Equipment documents and information literature to be delivered to the Government after Delivery Acceptance Appendix A Conceptual Block Diagram of Electronic Navigation Equipment Part VII Technical Specification Supply of Two Units of Speed Boats for Marine Department Page 3 of 37
12. Wing Yip Engineering Works Ltd Lot 145 64 Tam Kon Shan Road Tsing Yi N T Hong Kong 852 2786 3906 852 2781 2626 852 9236 9939 852 9238 0502 852 2332 2511 Clement Ngai Ngai Yee Ming Woo Cheng Mechanical Engineering Factory Ltd G F 195 Tai Kok Tsui Road Kowloon Hong Kong Yiu Lian Dockyards Ltd No 1 7 Sai Tso Wan Road Tsing Yi Island N T Hong Kong 852 2744 4113 852 2307 6131 852 9016 4527 852 2436 7728 852 2436 7800 852 2436 0679 852 2436 0671 852 2436 0690 852 2744 4632 852 2310 4884 852 2436 0712 852 2436 0590 Cheng King Yin Ng Yuen Biu Cheung Wai Yin art lechnical specifications Annex 7 List of Government Dockyard Contractors Item HI Hull Deck amp Tailshaft Group IT Page l of 1 Tender Ref Marine Department Shipbuilding Tender No 3 2015 Part VII Annex 8 Conditions for Official Sea Trial 1 Official Speed Trial Conditions at Speed Trial 1 Person Onboard 6 Persons 2 Deadweight 75 kg x 6 500 kg 3 Fuel Petrol 40 50 of Fuel Tank 4 Other Equipment 100 kg 5 Sea Conditions wind speed below 11 knots 6 Others All the machinery and equipment as required in the Technical Specifications shall be fully installed onboard The propulsion unit trim angle or other hull trim devices if installed shall be adjusted to provide maximum full throttle speed short of excessive porpoising or prop
13. dry bulb for 50 relative humidity when the ambient air temperature is 33 C dry bulb at 85 relative humidity with full complement onboard 28 3 The air conditioner shall be of a proprietary make with local control in wheelhouse 28 4 The refrigerant shall be CFC and HCFC free 28 5 Remote emergency stop buttons in the wheelhouse shall be provided to stop the air conditioning units in an emergency 29 Requirements for Electrical System 29 1 General Requirements 29 1 1 Any electrical installation shall conform to IEEE or other standard and rule acceptable by MD 29 1 2 The system type shall be insulated two wire Direct Current DC system The hull shall not be used as a current carrying conductor 29 1 3 Protective devices such as circuit breakers or fuses shall be provided at the source of power e g the switchboard to interrupt any overload current in the circuit conductors before heat can damage the Part VII Technical Specification Page 18 of 37 Supply of Two Units of Speed Boats for Marine Department Tender Ref Marine Department Shipbuilding Tender No 3 2015 29 1 4 29 1 5 29 1 6 29 1 7 29 1 8 29 1 9 29 1 10 29 1 11 29 1 12 29 1 13 29 2 Batteries 29 2 1 29 2 2 29 2 3 29 2 4 29 2 5 29 2 6 29 2 7 29 2 8 29 2 9 29 2 10 29 2 11 conductor insulation connections or wiring system terminals All DC equipment shall function over a voltage range at the battery terminals as
14. 28 176 Jerusalem Jerusalem ILS 1 837 Jordan Amman JOD 276 Aqaba JOD 178 Dead Sea Jordan Valley JOD 227 19 Amendment No 8 19 2015 Tender Ref Marine Department Shipbuilding Tender No 3 2015 Annex 4 10 First 28 nights Thereafter Country Currency City Petra JOD 213 Others JOD 178 All rates to be Kazakhstan reduced by 10 Almaty KZT 57 425 for stay in any one Aktau KZT 55 608 city Astana KZT 67 783 Others KZT 42 887 Kenya Nairobi KES 36 604 Lamu KES 33 926 Malindi KES 32 230 Mara Area Region KES 27 498 Mombasa KES 24 195 Mt Kenya Area KES 30 623 Nanyuki KES 5 178 Watamu KES 28 748 Others KES 17 320 Kiribati Christmas Island AUD 161 Tarawa AUD 165 Others AUD 165 Korea Seoul WON 332 343 Busan WON 340 838 Changwon WON 229 349 Cheju WON 361 012 Chinju WON 186 877 Chongju WON 150 776 Chonju WON 268 635 Chung Ju WON 174 135 Incheon WON 301 551 Kimhae WON 162 455 Kumi WON 220 854 Kwangju WON 242 090 20 Amendment No 8 20 2015 Tender Ref Marine Department Shipbuilding Tender No 3 2015 Annex 4 10 First 28 nights Thereafter Country Currency City Kyongju WON 279 253 Masan WON 165 641 All rates to be Pyeongchang WON 347 209 reduced by 10 Pyongtaek WON 173 073 for stay in any one Sokcho WON 242 090 it Taegu WON 231 472 A Taejon WON 233 596 Uijongbu WON 151 837 Ulsan WON 341 900 Others WON 151 837 Kosovo Pristina EUR 149 Others EUR 81 Kuwait Kuwait City K
15. 28 nights Thereafter Country Currency City Aswan EGP 1 623 Luxor EGP 1 637 All rates to be Sharm el Sheikh EGP 1 623 reduced by 10 Others EGP 1 330 for stay in any one El Salvador city San Salvador USD 221 Others USD 99 Equatorial Guinea Malabo XAF 193 533 Others XAF 193 533 Eritrea Asmara ERN 3 300 Others ERN 1 215 Estonia Tallinn EUR 189 Others EUR 155 Ethiopia Addis Ababa ETB 7 980 Others ETB 1 736 Falkland Islands Falkland Islands FKP 131 Faroe Islands Faroe Islands DKK 2 184 Fiji Suva FJD 422 Korolevu FJD 312 Nadi FJD 599 Natadola FJD 1 104 Sigatoka FJD 478 Others FJD 422 Finland Helsinki EUR 290 Others EUR 235 11 Amendment No 8 11 2015 Tender Ref Marine Department Shipbuilding Tender No 3 2015 Annex 4 10 First 28 nights Thereafter Country Currency City France Paris EUR 452 All rates to be Bordeaux EUR 306 reduced by 10 Cannes EUR 496 for stay in any one Deauville EUR 411 city Lyon EUR 312 Marseille EUR 333 Montpellier EUR 331 Nice EUR 321 Strasbourg EUR 341 Toulouse EUR 322 Others EUR 249 French Guiana French Guiana EUR 240 French Polynesia French Polynesia XPF 39 858 Gabon Libreville XAF 247 639 Others XAF 164 919 Georgia Tbilisi GEL 599 Ajara Region GEL 509 Borjomi GEL 284 Gudauri GEL 344 Kutaisi GEL 283 Others GEL 237 Germany Berlin EUR 289 Boeblingen EUR 297 Bonames EUR 346 Bonn EUR 259 Bremen EUR 281 Cologne EUR 312 Dresden EUR
16. 643 Russia Moscow RUB 19 630 Saint Petersburg RUB 19 273 Sochi RUB 20 106 Vladivostok RUB 13 285 Yuzhno Sakhalinsk RUB 14 673 Others RUB 8 923 Rwanda Kigali RWF 199 675 Akagera RWF 170 068 Gisenyi RWF 112 920 Ruhengeri RWF 118 428 Others RWF 112 920 Saint Helena Saint Helena SHP 43 Saint Kitts and Nevis Saint Kitts and Nevis XCD 1 051 Saint Vincent and the Grenadines Saint Vincent and the Grenadines XCD 673 Samoa Islands Samoa WST 694 San Marino San Marino EUR 194 30 Amendment No 8 30 2015 Tender Ref Marine Department Shipbuilding Tender No 3 2015 Annex 4 10 First 28 nights Thereafter Country Currency City Sao Tome and Principe Principe STD 5 911 053 All rates to be Sao Tome STD 5 252 116 reduced by 10 Saudi Arabia for stay in any one Riyadh SAR 1 819 city Dhahran Area SAR 1 422 Eskan SAR 473 Jeddah SAR 1 587 Medina SAR 792 Taif SAR 773 Others SAR 1 587 Senegal Dakar XOF 159 720 Mbour XOF 105 093 Others XOF 83 762 Serbia Belgrade RSD 33 200 Others RSD 13 336 Seychelles Seychelles SCR 5 936 Sierra Leone Freetown SLL 857 025 Others SLL 417 525 Singapore Singapore SGD 578 Slovak Republic Bratislava EUR 271 Zilina EUR 151 Others EUR 178 Slovenia Ljubljana EUR 237 Portoroz EUR 232 Others EUR 237 31 Amendment No 8 31 2015 Tender Ref Marine Department Shipbuilding Tender No 3 2015 Annex 4 10 First 28 nights Thereafter Country Currency Ci
17. Cote D Ivoire Abidjan XOF 199 260 Yamoussoukro XOF 90 005 Others XOF 81 161 Croatia Zagreb HRK 1 727 Cavtat HRK 2 527 Dubrovnik HRK 2 527 Split HRK 1 987 Others HRK 1 727 Cuba Havana CUC 188 Guantanamo Bay CUC 84 Holguin CUC 142 Matanzas CUC 144 Santiago CUC 147 Trinidad CUC 139 Others CUC 125 Cyprus Nicosia EUR 253 Akrotiri EUR 290 Limassol EUR 290 Paphos EUR 263 Others EUR 226 Czech Republic Prague CZK 9 066 Brno CZK 6 059 Others CZK 4 751 9 Amendment No 8 9 2015 Tender Ref Marine Department Shipbuilding Tender No 3 2015 Annex 4 10 First 28 nights Thereafter Country Currency City Democratic Republic of The Congo Kinshasa CDF 375 738 All rates to be Bukavu CDF 225 813 reduced by 10 Goma CDF 184 167 for stay in any one Lubumbashi CDF 243 397 city Mbuji Mayi Kasai CDF 168 434 Others CDF 173 061 Denmark Copenhagen DKK 2 402 Aalborg DKK 2 119 Lyngby DKK 2 402 Odense DKK 2 213 Others DKK 2 154 Djibouti Djibouti City DJF 60 603 Others DJF 27 369 Dominica Dominica XCD 597 Dominican Republic Santo Domingo DOP 10 876 La Romana DOP 11 616 Puerto Plata DOP 6 874 Sosua DOP 6 874 Others DOP 8 266 Ecuador Quito USD 265 Cuenca USD 202 Galapagos Islands USD 576 Guayaquil USD 273 Manta USD 179 Others USD 202 Egypt Cairo EGP 1 909 Alexandria EGP 1 644 10 Amendment No 8 10 2015 Tender Ref Marine Department Shipbuilding Tender No 3 2015 Annex 4 10 First
18. General Arrangement Supply of Two 2 Speedboats for MD Page 1 of 1 Tender Ref Marine Department Shipbuilding Tender No 3 2015 Part VII Annex 4 Implementation Timetable Milestones Milestone Completion Date Item 1st Vessel Item 2 2nd Vessel Issuance of Notification of Conditional Acceptance To be advised after Tender Evaluation Contract Date the date of the last party signing the Articles of Agreement Kick Off Meeting The date when the last party signs the Articles of Agreement The Government will not sign the Articles Agreement until and unless the Contractor fulfils all of the conditions precedent as specified in Clause 25 2 of the Conditions of Contract save to the extent waived by the Government if any To be held within one month after the Contract Date at Government Dockyard or Contractor s Shipyard Completion of hull structures including deckhouse Completion of installation of engines propellers and steering system Conduct of all tests inspections and trials as part of the Technical Acceptance including the Official Sea Trial Conduct of the on site commissioning tests for the electronic navigation equipment on the Vessel as part of the Technical Acceptance The Contractor shall propose the completion dates of Milestones 4 7 for GNC approval in one month after the Contract Date Vessel Ready for Use including without limitation
19. Naval Architecture Professional Institutions and supported by a number of professional and technical staff who shall have considerable years of experience in design and construction of vessel 3 2 The Tenderer s shipyard possesses the essential shipbuilding and workshop facilities such as lifting gears hull construction and calibration equipment machinery installation and calibration equipment and vessel launching or slipping facilities E 3 3 The Tenderer must fulfill the essential requirement concerning experience in vessel design and construction as specified in Item 1 of Annex C Essential Requirements to the Conditions of Tender E 3 4 The Tenderer must fulfil the essential requirement concerning experience in vessel design and construction as specified in Item 1 of Annex C Essential Requirements to the Conditions of Tender 3 5 The Vessel s design and construction shall be well planned 3 6 The shipyard of the Tenderer has been awarded with a valid and subsisting Certificate of Quality Management System ISO9000 issued by a Recognised Organisation as at the Tender Closing Date 4 Statement of Purposes of the Vessel The Vessel will be used by the Harbour Patrol Section HPS of Marine Department anywhere within Hong Kong waters The operational purpose of the Vessel is to perform patrol duties at shallow and or congested waters with required speed and maneuverability in Hong Kong Waters 5 Operating Profile and Minimum Life
20. No 3 2015 Society AWS or other international standards or rules acceptable to MD Welded Joints shall be carefully designed and constructed to conform to the latest established standards to prevent fatigue failure Cutting for edge preparation shall be performed by gualified person to achieve correct angle shape and smooth finish of the edges Only gualified welders shall perform the welding work Certification of the gualifications of each individual welder shall be submitted by the Contractor Welds installed using unqualified procedures or welding performed by non certified welders shall be subject to removal by the Contractor at his own expense For the structure fabrication this shall include but not be limited to the following 7 4 1 Inventory of incoming material consumable components and machinery 7 4 2 Traceability procedures for materials together with traceability identification codes which shall be serial and indexed to the controlled manufacturing procedures 7 4 3 Lofting cutting fit up welding forming and dimensions of structural components 7 4 4 Welding and inspection procedures identifying clearly the type and extent of NDT inspection carried out on the Vessel structure normally not more than 10 of Ultrasonic Test UT and Radioactive Test RT is required 7 4 5 Welding and inspection personnel qualification and certification 7 4 6 Welding machining measuring and inspection equipment maintenance and calibration
21. Office 2013 Standard Traditional Chinese i Printer Multi Functional Laser Printer Copy Print and copy which connect to PC through USB the print amp copy speed at least 20 pages per minutes and support auto double sides printing copying and scanning 36 5 2 2 ECS software a An ECS software Orac Master G2 must be installed in the PC running Windows Operating System 7 Professional or above b ENC format Capable of reading and loading ENC data files in IHO S 57 standard and updatung the files where necessary c GPS signals Capable of working with standard GPS DGPS receiver NMEA 0183 format d Navigation functions Capable of displaying normal navigational functions for distance bearing calculations and route planning e Audio alarm Capable of having voice output of anti ground and anti collision warnings f Chart loading Automatic loading of charts depending on own vessel s position and display scale g Head up mode Capable of showing both north up and head up mode h Safety display Capable of adjusting chart colour to the safety depth i Intuitive user interface Built in ship handling simulator j Additional chart region Capable of inputting additional chart regions k Measurement Capable of measuring bearing and range D Scale range 0 125nm to 128nm 36 6 Magnetic Compass and Fluxgate Compass 36 6 1 The Contractor shall provide one magnetic compass and also one fluxgate compass with digital d
22. Tender Ref Marine Department Shipbuilding Tender No 3 2015 Chapter 1 General Provision 1 Introduction 1 1 This document or Technical Specifications TS sets out the requirements of the Government in relation to the two 2 speedboats hereinafter referred to as Vessel for the use by the Hong Kong Marine Department hereinafter referred to as MD or user department For the avoidance of doubt references to Vessel shall mean each of these two speedboats 1 2 Tenderers shall note that all the specifications stated in this Part VII of the Tender Documents this Part are classified and labelled as follows 1 2 1 Essential Requirements E and 1 2 2 Those specifications that are not labelled with E shall equally form part of the Contract but the Government will not conduct any check at tendering stage to determine if the products offered comply with these specifications 1 3 All specifications identified as E are Essential Requirements As part of the tender evaluation during the tendering stage the Tenderer shall submit all the information sufficiently detailed to substantiate that the product and the services offered meet the Essential Requirements as stipulated in these TS failing which its tender will not be considered further 14 All Technical specifications which are not classified as Essential Requirements shall also form part of the Contract and be of equal materiality and importance upon the award of the
23. Vessel in order Part VII Technical Specifications Annex 1 Warranty Services and Guarantee Slipping Page 2 of 4 Supply of Two 2 Speedboats for Marine Department Tender Ref Marine Department Shipbuilding Tender No 3 2015 to repair or replace the same or another Warranty Item the Contractor shall obtain the written advance consent of the Government to the proposed modification Throughout the Warranty Period the Contractor shall maintain an inventory of spare parts which shall be the same items as listed in Schedule 8 and in the same quantity in the shipyard of the Contractor or of the GRSS appointed by it and which the Contractor or its GRSS shall use for performing the Warranty Services The Government will not provide its own inventory of the Critical and Consumable Parts to the Contractor for the provision of the Warranty Services Updated Upgraded Information It is expected that during the Warranty Period certain Warranty Item may be modified or changed All documentation affected by this change must be updated to reflect the new situation All the support documentation such as the Vessel inventory list job information and maintenance scheduling in relation to these modification and changes shall be provided at the expiry of the Warranty Period 2 Guarantee Slipping 2 1 As stated in the section Warranty above Guarantee Slipping shall be carried out at the end of the original Warranty Period regardless of any subsequ
24. XAF 149 311 Douala XAF 143 589 5 Amendment No 8 5 2015 Tender Ref Marine Department Shipbuilding Tender No 3 2015 Annex 4 10 First 28 nights Thereafter Country Currency City Limbe XAF 116 016 Others XAF 90 003 All rates to be Canada reduced by 10 Ottawa CAD 308 for stay in any one Banff CAD 501 city Calgary CAD 439 Dartmouth CAD 331 Edmonton CAD 331 Fort McMurray Alberta CAD 338 Fredericton CAD 305 Gander Newfoundland CAD 300 Halifax CAD 331 London Ontario CAD 234 Mississauga CAD 221 Moncton CAD 317 Montreal CAD 353 Nanoose Bay CAD 267 Northwest Territories CAD 235 Prince Edward Island CAD 339 Ouebec CAD 439 Regina Saskatchewan CAD 317 Richmond CAD 311 Saskatoon Saskatchewan CAD 311 Sidney CAD 318 St John s Newfoundland CAD 372 Toronto CAD 336 Vancouver CAD 386 Victoria CAD 318 Winnipeg CAD 356 Others CAD 300 Cayman Islands Cayman Islands KYD 249 6 Amendment No 8 6 2015 Tender Ref Marine Department Shipbuilding Tender No 3 2015 Annex 4 10 First 28 nights Thereafter Country Currency City Central African Republic Bangui XAF 131 103 All rates to be Others XAF 131 103 reduced by 10 Chad for stay in any one Ndjamena XAF 194 573 city Others XAF 142 028 Chagos Archipelago Chagos Archipelago GBP 50 Chile Santiago CLP 170 970 Others CLP 162 003 China Beijing RMB 2 320 Changchun RMB 1 643 Chengdu RMB 1 483 Chongqing RMB 1 120 Dalian RMB 1 686 F
25. be brought to SS GNC s attention If there is any disagreement between the parties which cannot be resolved during the Delivery the Lead Project Surveyor must inform SS GNC immediately 3 Authority and Responsibility When the vessel s is about to be delivered to the Government Dockyard the Lead Project Surveyor is responsible for liaising with and to notify GMD SSSM SFM if manned by MD crew and the User Department He is also responsible for ensuring the acceptance of the delivery of the vessel s is in accordance with the Contract and the procedures laid down in DAP Part VII Technical Specifications Annex 9 Delivery Acceptance Procedures Page 1 of 2 Tender Ref Marine Department Shipbuilding Tender No 3 2015 The Project Surveyors are responsible for checking the inventory onboard and making sure the inventory is also checked by the User Department where appropriate and SFM or their designated Officers if manned by MD crew Within this context S S GNC is responsible for checking the hull amp general deck and hull outfitting items and S E GNC is responsible for checking all machinery electrical and electronic items GNC Inspectors assigned by SS GNC for the project are responsible for assisting the Project Surveyors in the acceptance of the vessel The Lead Project Surveyor is responsible for informing the Contractor and to report to SS GNC of any item s which does not comply with the Contract specification at the
26. cabin sound and heat insulation system diagram Main engines and generator sets arrangement and sitting plans and drawings of their fuel lines and exhaust gas piping and arrangement Vessel ventilation drawings for the Wheelhouse Cabins and other spaces Main fuel oil tank drawing and its associated piping and manifold s and filling overflow and ventilation system Freshwater tank and its associated piping arrangement Fuel oil tank s and its associated piping system Drawings for anchor windlass and the anchoring system Life saving appliance arrangement plan and Fire Safety Plan Distress signals alarm systems and internal external communication arrangement and system plan Navigational lights sound and signal diagrams and any other external lighting arrangement plan Vessel overall lighting arrangement and light control plan Vessel alarm and signals internal communication systems and public address systems plan General Layout and Arrangement drawing of the air conditioning system Refrigerant Piping Layout drawing of the air conditioning system Air conditioning Load calculation Documents to be provided by the Contractor In not less than one 1 month before the Delivery Acceptance of the Vessel the Contractor shall provide GNC MD for GNC acceptance a list of all documents to be provided When the Vessel is delivered to the Government Dockyard the Contractor shall deliver to the Government all the technical informati
27. colour photographs showing the profile of the Vessel in HKSAR waters shall be provided upon Delivery Acceptance 38 6 Certificates and Reports Copies of the following documents 1 original with 2 copies and one softcopy stored in CD ROM or USB memory stick filed in clear folders shall be forwarded to MD at the time of Delivery Acceptance 38 6 1 Associated test certificates 38 6 2 Test performance certificates of equipment e g electronics switchboards etc 38 6 3 Petrol outboard engine performance test certificates 38 6 4 Complete record of the trial commissioning tests 38 6 5 Original copy of the warranty certificates of all machineries equipment and apparatus of the Vessel valid for 12 months from the date of Acceptance Certificate of the Vessel 38 6 6 Certificates of light and sound signalling equipment Part VII Technical Specification Page 36 of 37 Supply of Two Units of Speed Boats for Marine Department Tender Ref Marine Department Shipbuilding Tender No 3 2015 38 6 7 Buildercertificates 38 6 8 Certificates of building material 38 6 9 Deviation card for compass after adjustment in the HKSAR 38 6 10 Hull construction material issued by MD recognized Classification Society 38 6 11 Any other certificates as appropriate 38 7 Ship Model Tenderer is required to quote a separate price for the supply of one model which shall be built to scale scale 1 25 that represents in detail of the ship for display and t
28. follows 12 volt system 10 5 V to 15 5 V 24 volt system 21 V to 31 V The length and cross sectional area of conductors in each circuit shall be such that the calculated voltage drop shall not exceed 10 of the nominal battery voltage for any appliance when every appliance in the circuit is switched on at full load Switches and controls shall be marked to indicate their use unless the purpose of the switch is obvious and its mistaken operation will not cause a hazardous condition Each cable shall be clearly labelled and carries its own unique identification code The accommodation area requires 220V AC power sockets only for the portable apparatus and the domestic equipment etc A system of 220V AC and 24V DC power sockets shall also be available on the fore and aft ends of the Vessel on the weather deck and in the fore peak of the Vessel Each socket outlet shall be integrated with an On Off switch to facilitate local switching of the electrical equipment The 220V AC socket outlets shall be supplied with 13A 3 square pin fused plugs The 24V DC socket outlets shall be supplied with fused plugs The Contractor shall submit a layout plan showing the exact locations of the Equipment All Equipment shall be accessed easily and safely for inspection and maintenance Essential drawings and detailed particulars such as the rating and capacity type of all electrical Equipment as well as the wiring circuit breakers lighting and sockets etc
29. has been served on the Contractor by MD 1 8 Extension of Warranty 1 8 1 The Warranty Period for any Warranty Item shall be suspended whilst and if the Contractor fails to repair and correct satisfactorily the defects in such Warranty Item within 7 working days counting from the relevant fault report is first issued 1 8 2 Warranty Items which are electronic equipment sub assemblies modules or components and which are replaced during the Warranty Period shall have a new warranty period of one year commencing from the date of replacement 1 8 3 In relation to a Warranty Item references to Warranty Period shall be construed to include such extended warranty period as mentioned in 1 8 1 and or 1 8 2 above depending whichever is applicable 1 9 Recurrent Defects During the Warranty Period should a second and similar defect arise in relation to a Warranty Item this shall be construed as conclusive evidence of the Warranty Item s unsuitability for the purpose intended and the Contractor shall take immediate steps to conduct a thorough investigation jointly with MD at the Contractor s expense to ascertain the reasons for any such defect and shall forthwith at MD s option and the Contractor s expense procure and deliver another replacement Warranty Item with a new design suitable for the purpose intended to replace the original defective Warranty Item 1 10 In the event that the Contractor proposes to modify any Warranty Item or any part of the
30. leakage when using a leak detection method other than the pressure drop method 25 4 1 2 Pressure Type Test and Pressure Impulse Type Test A pressure test and pressure impulse test from representative of the tank series type A type approval certificates shall be submitted 26 Freshwater System 26 1 The capacity of the stainless steel SS 316 freshwater tank shall not be less than 100 litres The freshwater tank shall be an independent tank fitted with the following a Inspection cleaning access cover b Filling sounding pipe and c Air pipe 26 2 The freshwater tank shall not be directly adjacent to any other tanks The tank shall be hydraulically tested to the Classification Society s rule requirements One sounding tape or rod calibrated in litres shall be supplied A contents gauge for the tank shall be fitted in the wheelhouse 26 3 Domestic freshwater piping shall be of copper where exposed Precaution must be taken to avoid galvanic corrosion to the system and adjoining material and avoid the use of health affected material 26 4 Cold freshwater taps completed with PVC braided reinforced transparent hoses shall be fitted on the main deck aft and wheelhouse top for cleansing purposes 26 5 The pressurised unit shall include a starter pressure switch pressure gauge relief valve and suction valves together with a sight level gauge mounted on the pressurised tank The freshwater pump shall cut in and cut out automatically depe
31. on Clause 36 12 of Chapter 2 of Part VII 6 3 DGPS Details of the inspections have to be discussed in the Kick Off Meeting 6 4 Electronic Navigational Chart System 6 5 Public Address Broadcasting System 6 6 Inter communication System 6 7 Fixed Radio Phone System 6 8 Installation Space Cabling 7 Final Inspection and Trial 7 1 Mock Up Inspection for Control Console Details of the inspections have to be discussed in the Kick Off Meeting 7 2 Verification of Principal Dimension 7 3 Inclining Experience 74 Verification of Draught Marks Part VII Technical Specifications Annex 6 Main Inspection Items Supply of Two Units of Speed Boats for Marine Department Page 2 of 3 Tender Ref Marine Department Shipbuilding Tender No 3 2015 7 5 Functional Tests of Eguipment 7 6 Official Sea Trial The Official Sea Trial shall be conducted in HKSAR as part of reguirements of the Technical Acceptance 7 6 1 Official Speed Trial Details of the inspections have to be discussed in the Kick Off Meeting 7 6 2 Performance Test 7 6 3 Manoeuvrability Tests 7 6 4 Crash Stop Tests 7 6 5 Astern Running Emergency Steering Test 7 6 6 Anchor Test 7 6 7 Engine Repeat Starting Test 7 6 8 Noise Level Test 7 7 Bottom Survey on the Slipway at HKSAR 8 Training Plan 8 1 Training for Operators Details of the training have to be discussed in the Kick Off Meeting 8 2 Training for Maintenance Staff 8 3 O
32. priority devices being located in prime positions Controls shall ideally be positioned between elbow and shoulder height Instrument panels and display screens shall be ergonomically positioned for operator comfort without any impediment to his visibility Steering Control Wheel shall be provided with non slip steering wheel e Engine Throttle Control Head shall be provided on the right hand side of the steering wheel e Engine Monitoring Panel e Engine Start Control e Loudhailer Control Unit amp Microphone e Compass e Electric Horn e Siren and Flashing Beacon Control Panel e Navigation Lights Search Lights and Flood Lights Switch Panel e GPS Receiver e Radar Chart Plotter Control and Displays e UHF mobile transceiver All indication lights illumination of instrumentation gauges and panel lighting within the console area shall be fitted with dimmers for day and night operation One magnetic compass shall be installed directly in front of the coxswain The control consoles shall have sufficient leg room Part VII Technical Specification Page 12 of 37 Supply of Two Units of Speed Boats for Marine Department Tender Ref Marine Department Shipbuilding Tender No 3 2015 13 Foldable Mast To be satisfied air draught 2 95m limit the Mast shall not only be designed to be rigid during normal operation but also folded operate by one person in a safe manner at sea Drawing with the operating mechanism shall be submitted
33. shall be provided Setting of the alarm depth shall be at the front panel of the equipment 36 2 4 The electronic accuracy of depth reading shall be better than 5 of full scale range 36 2 5 The peak to peak transmitting pulse power of the transducer shall not be less than 200 watts and the nominal operating frequency shall be 200 kHz 36 2 6 There shall be an isolating switch to switch off the recorder in case of shortage of recording paper but the equipment for sensing and indicating the depth shall be still operating and functioning as in normal working condition Marine Radar 36 3 1 General Requirements 36 3 1 1 The equipment shall be a relative motion high performance radar suitable for small vessels and comprises a transceiver an antenna and a colour display unit suitable for bright daylight and night viewing 36 3 1 2 The transceiver shall be housed in the scanner unit and shall be designed for aloft mounted construction and capable of satisfactory operation at high wind speeds The scanner assembly shall be housed in a weatherproof housing 36 3 1 3 The radar scanner unit shall be installed well clear of obstruction to minimise undue interference and Non Ionizing Radiation NIR hazards Care shall also be taken to ensure the scanner mounting does not give excessive shadow sectors for navigation lights 36 3 1 4 Complete interface kit shall be provided to interface the radar for the Fluxgate Compass and GPS DGPS The radar shall have inter
34. the passing of the Technical Acceptance On or before the Delivery Date applicable to the same Vessel Delivery Date The Delivery Date for the Vessel shall be no later than the date set out in Schedule 2 Delivery Schedule for that Vessel Part VII Technical Specifications Annex 4 Implementation Timetable Milestones Supply of Two 2 Speedboats for Marine Department Page 1 of 1 Tender Ref Marine Department Shipbuilding Tender No 3 2015 Part VII Annex 5 Implementation Timetable Drawing Submission ItemNo_ Drawings Approval Completion Date Item 1 Item 2 1st vessel 2nd vessel 1 General Arrangement Plan 2 Lines Plan 3 Major Structural Construction Plans 4 Engine Mounting Arrangement 5 Power Speed Estimation and Curve 6 Intact and damaged Stability Plan 7 Details of draught marks with locations range datum reference and detailed description of marking method 8 Cabin layouts 9 Inclining Experiment Report 10 Details of Navigational Communication Equipment 11 Details of Deck Equipment Outfitting Furniture etc 12 Details of Outboard Petrol Engines 13 Control Console Arrangement and Schematic Diagram 14 Instrumentation and Control System 15 Calculation of Fuel Capacity 16 Details of Electrical and Electronic Equipment 17 Electrical Load Calculations 18 Schematic Layout of Electrical Circuits 19 Paint Schedu
35. time of delivery and he should ensure the Contractor has acknowledged the fact in writing The Project Surveyors should not sign any document until all details that constitute outstanding items are agreed in writing by the Contractor SMM SSSM and SFM and by the User Department where in the judgment of the Project Surveyor is necessary GNC staff is NOT authorized to sign any document regarding the safekeeping including mooring fuel and water contents of the vessel s delivered as this is not GNC s area of responsibility When signing the inventory document the Project Surveyors must ensure they are satisfied with the quantity and quality of the items listed in the Inventory List SS GNC is responsible for ensuring the Project Surveyors have carried out the acceptance of the vessel s in accordance with this DAP and report the Acceptance to GMD and AD GF Part VII Technical Specifications Annex 9 Delivery Acceptance Procedures Page 2 of 2 Tender Ref Marine Department Shipbuilding Tender No 3 2015 Part VII Annex 10 Definitions of Wave and Sea eth Description Wind speed an Sea conditions Land conditions lt 1 km h lt 0 3 m s Om lt 1 mph J 0 Calm Fin Flat Calm Smoke rises vertically lt ot 0ft lt 0 3 m s 1 1 5 5 km h 0 3 2 m s 0 0 2 m PT 1 3 mph Smoke drift indicates wind 1 Ligh
36. vent with flame trap on deck and discharge valve with remote operated quick closing device shall be provided 25 3 6 6 The tank support chocks or hangers shall either be separated from the surface of metal tanks by non metallic non hygroscopic non abrasive material or welded to the tank 25 3 6 7 An easily removable coarse strainer shall be built into the filling line 25 3 6 8 Baffles shall be provided the total open area provided in the baffles shall be not greater than 30 of the tank cross section in the plane of the baffle 25 3 6 9 Baffle openings shall be designed so that they do not prevent the fuel flow across the bottom or trap vapour across the top of the tank 25 3 6 10 The tank shall be designed or installed so that no exterior surface will trap water 25 3 6 11 Tank drains are not permitted on diesel fuel tank 254 Fuel oil Tank Tests 25 4 1 1 Leakage Test The tank shall be internally tested with a hydraulic pressure with all its accessories The test pressure shall be the greatest of 20 kPa 1 5 times the highest hydrostatic Part VII Technical Specification Page 17 of 37 Supply of Two Units of Speed Boats for Marine Department Tender Ref Marine Department Shipbuilding Tender No 3 2015 Pressure to which the tank may be subjected in service mazimum fill up height above tank top The static test pressure shall be applied for 5 min without pressure drop or rise After the test the test fuel tank shall not show any
37. 1 f 2 Watertight cable glands shall be provided in way of watertight bulkhead or deck penetration 36 11 f 3 Signal wiring shall be separated from power supply cables and housed in separate screened conduits or cable trunks 36 11 f 4 Cables and wirings shall run behind the compartment lining Where electric cables are necessary fitted on the decorative surface of bulkheads they are to be enclosed in proper metal conduits g Labelling and Marking 36 11 g 1 Each cable shall be clearly labelled and preferably carry its own unique identification code 36 11 2 Polarity of power cables shall be labelled 36 11 3 All cables shall be clearly labelled and carry its own unique identification code 36 12 Acceptance Test a The acceptance tests for each of the electronic navigation equipment specified in this paragraph 36 shall comprise the following 36 12 a 1 A bench acceptance test which includes functional tests and detailed measurements of the performance of the equipment to verify that each equipment complies with all the required performance specification 36 12 a 2 On site commissioning test shall be carried out by the Contractor in the presence of the Electrical and Mechanical Services Department s EMSD representatives after completion of the installation of each system on the Vessel The overall installation standard and operational features of each system shall be evaluated Part VII Technical Specification Page 32 of 37 Su
38. 10 Definitions of Wave and Page 2 of 2 Tender Ref Marine Department Shipbuilding Tender No 3 2015 Part VII Annex 11 Markings and Colour Scheme 1 Vessel s Name 1 1 The Vessel s name shall be permanently displayed at both sides of the cabin and on the hull The exact size and letters numbers will be provided by GNC 1 2 The wording and calligraphy should be in line with the one displayed on the existing HPS vessels The wording and size of the Vessel s name shall be agreed by MD including the colour to be used 1 3 Location and size of the Contractor s name plate fixed on the Vessel shall be agreed by MD 2 Colour Scheme 2 1 It is important that ALL colour used including fabrics for upholstery curtains floor tiles and furniture shall be approved by MD before installation 2 2 All colour samples will be submitted by the Contractor for approval before application 2 3 Piping colour codes will comply with BS 1710 1975 or equivalent and be approved by MD 24 Colour of draught marks name insignia and other colour markings etc will be provided as required by MD 3 Draught Marks Draught Marks should be provided at the port and starboard of stem and stern Draught marks shall be in Arabic numerals 100 mm high The marks shall be measured from the lowest point of the Vessel to the underside of the number markings The marks shall be spaced every 200 mm and shall be marked as follows Part VII Tec
39. 2 Protection guard bars at the rear and outside of the engines shall be provided for protecting the engines from external damage but not considered as a fixed permanent structure for LOA measurement The design and dimension shall be indicated in the GA that required to be submitted for MD approval before the Completion Date stipulated in Annex 5 to this Part 19 3 Working platforms for engine inspection purpose shall be fitted 20 Anchoring Mooring and Lifting Strong Points 20 1 All anchor swivel and mooring rope shall provide with certificate type approval certificate from HKMD recognised classification 20 2 One hot dip galvanized high holding power anchor with a galvanized swivel and 30m nylon rope shall be provided and stored at the recessed anchor stowage 20 3 Four heavy duty of double braid mooring rope in 28 mm dia shall be provided for Vessel 2 lengths each in 15 m and 30 m 20 4 The Vessel shall be provided with the 4 point Lifting Points which shall be designed to lift up the vessel without damaging to the vessel s hull 20 5 Mooring bollards shall be provided at bow and stern 20 6 Mooring cleats shall be provided at Port and Starboard side of hull 20 7 Load test shall be carried out for 4 lifting points of the vessel before delivery The design of 4 lifting points shall be submitted by classic approval 21 Engines 21 1 The Vessel shall be powered by the engines which shall be two marine four strokes outboard petr
40. 2 Ease access to in situ service and maintenance in Hong Kong 38 Information to be Provided Prior to and at Delivery Acceptance 38 1 Information provided prior to Delivery Acceptance 38 1 1 Detailed inventory list for the whole Vessel to be submitted to the Government for approval at the time as mentioned in paragraph 4 3 6 of Chapter 1 38 1 2 The inventory list shall cover all items specified in this Part including all Equipment and fitting down to major component unit level 38 1 3 Full details of each item includes 38 1 3 1 Itemname 38 1 3 2 Description 38 1 3 3 Type model 38 1 3 4 Quantity 38 1 3 5 Manufacturer 38 1 3 6 Manufacturer s reference number 38 1 3 7 Location in Vessel 38 1 3 8 Local agent supplier address telephone and fax numbers 38 1 3 9 Order time 38 1 3 10 Shelf life 38 1 3 11 Unitcost 38 1 4 FOUR copies of the inventory list shall be provided 38 2 As Fitted drawings and other information shall be supplied The Contractor shall supply the following items upon Delivery Acceptance of the Vessel 38 2 1 4 complete sets of paper print drawings of the Vessel and soft copy dwg format n CD ROM or USB memory stick as per the Vessel delivered 38 2 2 4 complete sets of paper print as fitted electrical schematic cabling wiring and single line diagrams for electrical equipment installed onboard and conduit trunk route diagram 38 2 3 4 copies of ship equipment list for all bought
41. 250 newtons shall be classification society approval type and relative certificate to be submitted 16 Toilet 16 1 16 2 Toilet arranged inside cabin aft and a black water tank shall be arranged under deck Toilet access door shall be from outside of cabin A toilet compartment with natural light for illumination and non slip floor shall be provided and suitably fitted out with the followings 16 2 1 One stainless steel wash basin inside area not less than 320 x 220mm with cold freshwater supply tap 16 2 2 One mirror cabinet size 300 x 400mm approx 16 2 3 One marine type toilet with marine sized bowl electrical water pump and emergency manual double action piston pump for flushing purpose to the satisfaction of MD 16 2 4 Two stainless steel wall mounting hooks double clothes type 16 2 5 High quality plastic perforated grating floor 16 2 6 One electric exhaust fan 16 2 7 One paper towel rack 16 2 8 Stainless steel grip rails 16 2 9 One liquid soap dispenser 16 2 10 One paper towel waste bin 16 2 11 The toilet door shall be fitted with louvers and louvers cover at the lower portion 16 2 12 Grab rail shall be provided 17 Fender 17 1 17 2 17 3 17 4 17 5 A robust and permanent solid foam filled fender collarets shall be durable to withstand knife thrusts and direct impacts No air or inflatable fender will be accepted The fender shall be designed to absorb stresses applied to the Vessel whilst m
42. 286 12 Amendment No 8 12 2015 Tender Ref Marine Department Shipbuilding Tender No 3 2015 Annex 4 10 First 28 nights Thereafter Country Currency City Duesseldorf EUR 281 Echterdingen EUR 297 All rates to be Erfurt EUR 290 reduced by 10 Eschborn EUR 346 for stay in any one Esslingen EUR 297 city Frankfurt am Main EUR 346 Garmisch Partenkirchen EUR 170 Hamburg EUR 285 Hannover EUR 239 Heidelberg EUR 290 Herongen EUR 281 Hoechst EUR 346 Kalkar EUR 281 Koenigswinter EUR 259 Kornwestheim EUR 297 Leipzig EUR 269 Ludwigsburg EUR 297 Mainz EUR 290 Moenchen Gladbach EUR 281 Munich EUR 300 Nellingen EUR 297 Oberammergau EUR 170 Offenbach EUR 346 Roedelheim EUR 346 Sindelfingen EUR 297 Stuttgart EUR 297 Tuebingen EUR 297 Twisteden EUR 281 Wiesbaden EUR 276 Others EUR 259 Ghana Accra GHS 1 101 Takoradi GHS 938 Others GHS 476 13 Amendment No 8 13 2015 Tender Ref Marine Department Shipbuilding Tender No 3 2015 Annex 4 10 First 28 nights Thereafter Country Currency City Gibraltar Gibraltar GIP 101 All rates to be Greece reduced by 10 Athens EUR 268 for stay in any one Iraklion Crete EUR 218 city Others EUR 218 Greenland Nuuk DKK 2 514 Ilulissat DKK 2 349 Kangerlussuaq DKK 2 060 Thule DKK 1 641 Others DKK 1 859 Grenada Grenada XCD 784 Guadeloupe Saint Martin French Part EUR 161 Others EUR 124 Guatemala Guatemala City GTQ 1 711 Others GTQ 1 397 Guinea
43. 6 852 2742 1819 852 2431 2644 852 9094 5589 852 6933 2733 852 2433 0180 Philip Leung K F Leung Tsui Shek Yau Hop Kee Engineering Work Ltd SHX 508 Temporary Industrial Area Po Chong Wan Shum Wan Road Wong Chuk Hang Hong Kong 852 2785 9221 852 2785 9236 Lee Wai Ngung Kwong Sang Engineering Co Ltd G F 13 Hop Kwan Street Tai Kok Tsui Kowloon Hong Kong 852 2785 7879 852 2785 7550 852 9037 4890 852 2786 2510 Chan Leung Kan The Chans Shipyard Ltd Lot 22 23 Tam Kon Shan Road North Tsing Yi Island N T Hong Kong The Hong Kong Shipyard Ltd 98 Tam Kon Shan Road Ngau Kok Wan North Tsing Yi N T Hong Kong 852 2744 9113 852 2310 8272 852 9053 1211 852 2436 7188 852 2744 9283 852 2436 2011 Lam Kwan Chung Ma Chi Wai Tung Hing Ship Builder amp Engineering Works Ltd 9 Wai On Street G F Tai Kok Tsui Kowloon Hong Kong 852 9195 8155 852 9196 0117 852 2307 2533 852 2307 1629 852 2307 2637 Wong Tung Lam Cheung Sui Fan Tung Wo Engineering Co Ltd 2705 27 F New Treasure Centre 10 Ng Fong Street San Po Kong Kowloon Hong Kong 852 2328 3363 852 2391 3191 852 9486 2760 852 2328 3989 852 2398 1039 Lo Kee Sang Wang Tak Engineering amp Shipbuilding Co Ltd 3 F Wang Tak Building 85 Hing Wah Street West Lai Chi Kok Kowloon Hong Kong 852 2746 2888 852 6770 6578 852 2307 5500 K H Leung
44. 6 1 Switchboards shall be installed such that the control elements indicating instruments circuit breakers and fuses are readily accessible The terminal side shall be accessible 29 6 2 Connections and components on panel boards shall be in locations protected from the expected conditions in conformity with IEC 60529 29 6 2 1 IP 67 as a minimum if exposed to short term immersion IP 55 as a minimum if exposed to splashing water 29 6 2 2 IP 20 as a minimum if located in protected locations inside the craft 29 6 3 Panel boards switchboards shall be permanently marked with the nominal system voltage 29 6 4 A moulded case circuit breaker for shore connection box shall be provided on the main switchboard The shore connection box shall be capable of receiving 220V 1 phase 50 Hz current on a 2 wire system and the cables between the connection box and the main switchboard shall be of sufficient capacity to supply the necessary electrical equipment An earth terminal shall be provided for connection of the Vessel s earth to the shore earth An instruction sign shall be provided at the connection box to give full information of the system and the procedures for carrying out the connection In addition the circuit breaker on the main switchboard shall contain the following fittings 29 6 4 1 circuit with under voltage protection and interlocking device to ensure electrical isolation during the change over 29 6 4 2 Indication light for Shore Power A
45. 8 3 Critical and Consumable Parts 38 3 1 38 3 2 All items of Critical and Consumable Parts shall be delivered to the Government Dockyard as per the requirements stipulated in Schedule 2 Delivery Schedule of Part V All items supplied shall be identical in make quantity and size as they are installed on the Vessel upon Delivery Acceptance All items shall be properly documented preserved and packed 38 4 Ship Model Tools amp Test Equipment for ENE 38 4 1 38 4 2 Delivery of the ship model Item 6 of Schedule 1 to MD and all test and tool equipment for the ENE will be directly to EMSD Allitems shall be properly documented preserved and packed 38 5 Photographs 38 5 1 38 5 2 As Fitted Photographs 38 5 1 1 2 sets of colour prints 130 mm x 90 mm from different aspects to give an overall picture of the various parts areas of the Vessel shall be provided upon Delivery Acceptance 38 5 1 2 Each print shall be enclosed in a suitable album and labelled showing the position of the content Official Photographs 38 5 2 1 Four 4 framed colour photographs of picture size not less than 350 mm x 270 mm and frame size not less than 510 mm x 400 mm showing the profile of the Vessel in HKSAR waters shall be provided upon Delivery Acceptance 38 5 2 2 Four 4 200 mm x 150 mm colour photographs showing the profile of the Vessel in HKSAR waters shall be provided upon Delivery Acceptance 38 5 2 3 Four 4 150 mm x 100 mm
46. Amagasaki JPY 34 974 All rates to be Aomori JPY 23 243 reduced by 10 Asahikawa JPY 22 146 for stay in any one Ashiya JPY 36 399 city Awashima JPY 57 558 Beppu JPY 33 329 Chitose JPY 21 050 Fukui JPY 18 419 Fukuoka JPY 36 508 Fukuyama JPY 19 296 Gifu JPY 33 548 Hamamatsu JPY 27 628 Hiroshima JPY 27 628 Itazuke JPY 36 508 Izumisano JPY 32 671 Kagoshima JPY 28 615 Kanazawa JPY 22 694 Kitakyushu JPY 32 671 Kochi JPY 23 900 Komaki JPY 27 957 Kumamoto JPY 34 206 Kurashiki JPY 44 841 Kure JPY 26 970 Kushiro JPY 19 515 Kyoto JPY 42 758 Matsue JPY 18 967 Matsuyama JPY 27 628 Miyazaki City JPY 44 621 Morioka JPY 22 804 Nagasaki JPY 40 675 Nagoya JPY 36 070 Nara JPY 23 900 Narita JPY 31 904 18 Amendment No 8 18 2015 Tender Ref Marine Department Shipbuilding Tender No 3 2015 Annex 4 10 First 28 nights Thereafter Country Currency City Niigata JPY 20 721 Nishinomiya JPY 36 399 All rates to be Obihiro JPY 24 339 reduced by 10 Oita JPY 25 435 for stay in any one Okayama JPY 31 575 city Okinawa Prefecture JPY 35 851 Osaka Kobe JPY 34 974 Otsu JPY 29 163 Oyama JPY 20 502 Sapporo JPY 33 768 Sasebo JPY 18 857 Sendai JPY 31 685 Shiga JPY 29 163 Takamatsu JPY 23 023 Takayama JPY 29 492 Tokushima JPY 22 694 Tokyo To JPY 29 821 Tottori JPY 24 339 Toyama JPY 27 957 Toyonaka JPY 32 342 Tsu JPY 28 176 Wakayama JPY 29 382 Yamato JPY 25 326 Yokohama JPY 28 944 Yokota JPY 18 199 Yufuin JPY 30 369 Others JPY
47. Expectancy 5 1 The Vessel is required to be available for deployment at least 260 outings per year with each outing days to be used over 7 5 hours in which 2 hours shall be at maximum speed of 35 knots at Sea State 2 or below 5 2 The Vessel shall have a minimum life expectancy of 15 years from the issue date of the Acceptance Certificate 6 Stability 6 1 The Vessel is required to comply with the stability requirements stated in the Annex 2 of these Technical Specifications E 7 Hull 7 1 Hull Construction and Scantlings The stresses and scantling for all structural members shall be determined in according to the rules of a RO 7 2 Materials The hull construction material shall be new and of a type which has been certificated by a RO or other entities acceptable by MD Mill Certificates shall be obtained and records strictly maintained to match these to the various sections produced during Vessel manufacture 7 3 The Contractor shall carry out quality control throughout the construction of the Vessel by their quality control personnel 7 4 Welding and Fabrication All welding and fabrication shall be implemented according to the rules of a RO for example ABS Guide for Building and Classification High Speed Craft Section 15 Welding and Fabrication or American Welding Part VII Technical Specification Page 10 of 37 Supply of Two Units of Speed Boats for Marine Department Tender Ref Marine Department Shipbuilding Tender
48. KSAR When the generation use of calendars are employed for logging of reports activation off equipment or as any essential part of logic for the proper functioning of the system then the calendar generation shall function without any error or manual intervention for all leap years Part VII Technical Specification Page 23 of 37 Supply of Two Units of Speed Boats for Marine Department Tender Ref Marine Department Shipbuilding Tender No 3 2015 36 2 36 3 36 1 9 36 1 10 36 1 11 The circuit breaker for the electronic eguipment shall eguip with lockout device so that the breaker can be locked during the eguipment maintenance Lightning protection shall be provided and installed wherever applicable The lightning arresters for all outdoor antennas shall be installed at the antenna ends Eguipment supplied shall complete with all standards and or maker recommended accessories as required for normal operation Echo sounder and Depth Indicator 36 2 1 The equipment shall consist of a transducer and a digital depth indicator which is recessed mounted at the steering console and capable of providing readout of sea depth in feet fathoms and meters 36 2 2 The measuring depth shall be from 3 feet to 250 feet or equivalent in fathom or metre with at least 3 selectable ranges to indicate shallow mid and deep ranges The unit of measurement shall be selected at the front panel of the equipment 36 2 3 Shallow water audible alarms
49. P 229 Liverpool GBP 178 Loudwater GBP 188 Manchester GBP 206 Menwith Hill GBP 145 Oxford GBP 175 Reading GBP 233 Others GBP 168 United States of America N Alabama Montgomery USD 165 Others USD 165 Alaska Juneau USD 307 Anchorage USD 286 Others USD 307 American Samoa Pago Pago USD 295 Others USD 295 Arizona Phoenix USD 228 Others USD 228 Arkansas Little Rock USD 188 Others USD 188 37 Amendment No 8 37 2015 Tender Ref Marine Department Shipbuilding Tender No 3 2015 Annex 4 10 First 28 nights Thereafter Country Currency City California Sacramento USD 214 All rates to be Anaheim USD 268 reduced by 10 Berkeley USD 238 for stay in any one Los Angeles USD 268 city Mojave Desert USD 182 San Diego USD 274 San Francisco USD 390 Others USD 214 Colorado Denver USD 299 Colorado Springs USD 193 Others USD 299 Connecticut Hartford USD 222 Others USD 222 Delaware Dover USD 176 Others USD 176 Florida Tallahassee USD 179 Daytona Beach USD 180 Miami USD 285 Orlando USD 220 Ormond Beach USD 180 Pensacola USD 200 Others USD 179 Georgia Atlanta USD 249 Others USD 249 Guam Hagatna USD 311 Others USD 311 38 Amendment No 8 38 2015 Tender Ref Marine Department Shipbuilding Tender No 3 2015 Annex 4 10 First 28 nights Thereafter Country Currency City Hawaii Honolulu USD 364 All rates to be Others USD 364 reduced by 10 Idaho for stay in any o
50. R 2 481 762 Timika Irian Jaya IDR 3 917 291 Yogyakarta IDR 1 751 832 Others IDR 1 776 163 Iran Tehran IRR 4 138 345 Others IRR 4 138 345 Iraq Baghdad IQD 178 805 Erbil IQD 320 455 Others IQD 140 489 Ireland Dublin EUR 348 Cork EUR 251 Galway EUR 259 Others EUR 232 Israel Tel Aviv ILS 1 928 Eilat ILS 1 965 En Boqeq ILS 1 484 Haifa ILS 1 506 Herzliya Pituach ILS 1 704 Sedom ILS 1 484 Tiberias ILS 1 535 Others ILS 1 535 Italy Rome EUR 457 Bari EUR 243 16 Amendment No 8 16 2015 Tender Ref Marine Department Shipbuilding Tender No 3 2015 Annex 4 10 First 28 nights Thereafter Country Currency City Bologna EUR 368 Bolzano EUR 228 All rates to be Capri EUR 348 reduced by 10 Catania EUR 251 for stay in any one Como EUR 438 city Ferrara EUR 254 Florence EUR 374 Gaeta EUR 170 Genoa EUR 319 La Spezia EUR 227 Milan EUR 421 Modena EUR 243 Naples EUR 262 Palermo EUR 247 Pisa EUR 211 Pordenone Aviano EUR 146 Ravenna EUR 227 Reggio Emilia EUR 256 Rimini EUR 272 Siena EUR 348 Taormina EUR 251 Treviso EUR 269 Trieste EUR 298 Turin EUR 355 Venice EUR 472 Verona EUR 251 Vicenza EUR 146 Others EUR 287 Jamaica Kingston JMD 29 329 Others JMD 29 329 Japan Tokyo City JPY 43 415 Akashi JPY 34 974 17 Amendment No 8 17 2015 Tender Ref Marine Department Shipbuilding Tender No 3 2015 Annex 4 10 First 28 nights Thereafter Country Currency City Akita JPY 24 339
51. S DGPS receiver shall be input to the marine radar and display on the marine radar and the screen of the Electronic Chart System ECS The output of the receiver shall give the vessel position in a format compatible to marine radar in the NMEA 0183 format However connection of the radar system to the other systems supplied under this Contract via other standard interface types equivalent to NMEA 0183 is acceptable The system shall be provided with speed logs and electronic compass interface or gyro and its interface to support the dead reckoning mode operation if GPS satellite signal is absent for a period greater than 10 minutes Capable of input not less than 20 routes of 100 waypoints with 20 character alphanumeric names and icons Language to be used is English and desirably with Chinese Performance requirements 36 4 2 1 36 4 2 2 36 4 2 3 36 4 2 4 Display a Display unit True sunlight readable 640 x 480 pixel or better back lit LCD Display b NAV data 3 D panorama display c Position indication Latitude Longitude UTM d Position resolution 4 decimal places GPS Receiver a GPS Receiver Type Equipped with 8 channel parallel receiver or better b Frequency Range 1575 42 1MHz C A code L1 c Sensitivity 130 dBm or better d Dynamic Range 25 dB or better e Warm start fix time Less than 30 seconds f Cold start fix time Less than 3 minutes g Position Accuracy 15m or better h Trackin
52. Tender Ref Marine Department Shipbuilding Tender No 3 2015 Part VII Technical Specification IMPORTANT It is essential that the tenderer agrees to meet with all the Essential Requirements labeled as E stipulated in the Technical Specifications and indicates in the tender submission Otherwise the tender submission will not be considered Part VII Technical Specification Page 1 of 37 Supply of Two Units of Speed Boats for Marine Department Tender Ref Marine Department Shipbuilding Tender No 3 2015 Table of Contents Chapter 1 General Provisions NAYDNBWNKE Introduction Design and Construction Responsibility Warranty Services During the Warranty Period Acceptance and Delivery Survey and Inspection Official Sea Trial and Speed Requirements Support Services Chapter 2 Technical Specifications OMDAADANAWN e Introduction Rules and Regulations Shipyard Statement of Purposes of the Vessel Operating Profile and Minimum Life Expectancy Stability Hull Painting General Arrangement Deck Cabin Hand Holds and Grab Rails Consoles Foldable Mast Lockers Void Spaces Seating and Attachment Systems Toilet Fender Bow Transom and Stern Area Anchoring Mooring and Lifting Strong Points Engines Engine Installation Propeller Steering System Fuel System and fuel oil Tank Freshwater System Generator Set Air conditioning System Requirements for Electrical System Bilge System
53. UD 342 Darwin Northern Territory AUD 353 Exmouth AUD 414 Fremantle AUD 399 Hobart AUD 418 Melbourne AUD 460 Perth AUD 491 Richmond NSW AUD 372 Sydney AUD 429 Others AUD 342 Austria Vienna EUR 317 Graz EUR 321 Innsbruck EUR 314 Linz EUR 303 Salzburg EUR 331 Others EUR 314 Azerbaijan Baku AZN 283 Ganja AZN 169 Qabala AZN 166 Others AZN 140 Bahamas Nassau BSD 440 Andros Island BSD 236 Eleuthera Island BSD 255 Grand Bahama Island BSD 285 Others BSD 236 2 Amendment No 8 2 2015 Tender Ref Marine Department Shipbuilding Tender No 3 2015 Annez 4 10 First 28 nights Thereafter Country Currency City Bahrain Bahrain BHD 149 All rates to be Bangladesh reduced by 10 Dhaka BDT 22 414 for stay in any one Chittagong BDT 13 216 city Sylhet BDT 13 448 Others BDT 11 130 Barbados Barbados BBD 692 Belarus Minsk BYR 3 247 600 Others BYR 3 247 600 Belgium Brussels EUR 281 Antwerp EUR 267 Brugge EUR 200 Diegem EUR 281 Kleine Brogel EUR 176 Liege EUR 195 SHAPE Chievres EUR 174 Zaventem EUR 281 Others EUR 138 Belize Belize City BZD 417 Belmopan BZD 466 San Pedro BZD 486 Others BZD 417 Benin Cotonou XOF 128 504 Others XOF 76 478 Bermuda Bermuda BMD 513 Bhutan Bhutan BTN 24 226 3 Amendment No 8 3 2015 Tender Ref Marine Department Shipbuilding Tender No 3 2015 Annez 4 10 First 28 nights Thereafter Country Currency City Bolivia La Paz BOB 1 346 All rates to be C
54. WD 130 Others KWD 130 Kyrgyzstan Bishkek KGS 16 886 Issyk Kul Region KGS 10 425 Others KGS 6 950 Laos Vientiane LAK 1 704 737 Luang Prabang LAK 2 195 250 Others LAK 1 535 871 Latvia Riga EUR 205 Others EUR 205 Lebanon Beirut LBP 317 275 Others LBP 317 275 Lesotho Maseru LSL 1 885 Others LSL 2 189 21 Amendment No 8 21 2015 Tender Ref Marine Department Shipbuilding Tender No 3 2015 Annex 4 10 First 28 nights Thereafter Country Currency City Liberia Monrovia LRD 26 993 All rates to be Others LRD 10 614 reduced by 10 Libya for stay in any one Tripoli LYD 553 city Benghazi LYD 242 Misurata LYD 242 Sirte LYD 242 Others LYD 198 Liechtenstein Liechtenstein CHF 407 Lithuania Vilnius EUR 241 Palanga EUR 227 Others EUR 176 Luxembourg Luxembourg EUR 368 Macedonia Skopje MKD 12 430 Ohrid MKD 8 857 Others MKD 8 857 Madagascar Antananarivo MGA 630 332 Nosy Be MGA 566 501 Others MGA 444 158 Malawi Lilongwe MWK 96 269 Blantyre MWK 96 269 Mangochi MWK 81 610 Salima MWK 108 550 Others MWK 81 610 Malaysia Kuala Lumpur MYR 917 Kota Kinabalu Sabah MYR 616 22 Amendment No 8 22 2015 Tender Ref Marine Department Shipbuilding Tender No 3 2015 Annez 4 10 First 28 nights Thereafter Country Currency City Kuantan MYR 553 Langkawi MYR 897 All rates to be Melaka MYR 488 reduced by 10 Penang MYR 583 for stay in any one Others MYR 616 city Maldives Maldive
55. al reports shall be submitted h Al the above work shall be carried out by the local service agent of the engine manufacturers i All involved work procedures and specifications shall be carried out in compliance with the corresponding service manuals from original engine manufacturer jp Clean thoroughly cooling water passages and refit all to good order k Cooling water pump strip down the pumps clean and check wear down Renew all defective parts and refit all the parts to good order 2 2 1 3 Under water Fittings a Replace all zinc anodes b Inspect clean polish and coat propeller with oil c Inspect and clear all marine growth on all under water fittings 2 2 2 Hull and Deck Items if applicable 2 2 2 1 Clean off all marine growth Part VII Technical Specifications Annex 1 Warranty Services and Guarantee Slipping Page 3 of 4 Supply of Two 2 Speedboats for Marine Department Tender Ref Marine Department Shipbuilding Tender No 3 2015 2 2 2 2 2 2 2 3 2 2 2 4 2225 2 2 2 6 2 2 2 7 2 2 2 8 2 2 2 9 Renew all zinc anodes Repair damage paint properly and apply two coats of touch up primer one coat of touch up and one full coat of finishing paint to hull below waterline Repair damage paint properly to hull exterior above waterline and all other area including hull interior superstructure and fittings etc Apply two coats of touch up primer one coat of touch up and one full finishing coat as or
56. ance 6 9 1 Engine Repeat Starting Tests 6 9 2 Anchoring Test 6 9 3 Noise level Test Support Services 7 1 The Vessel must be designed for through life support and easy maintenance in the HKSAR based on an operation profile and minimum life expectancy as mentioned in Chapter 2 paragraph 5 1 2 The requirements specified in the above paragraph 7 1 shall apply to the main engines and all other Equipment installed in the Vessel 73 The above applies not only to main engine but also to all other Equipment installed in the Vessel Support and maintenance services must be available i e serviceable in Hong Kong in respect of all Equipment installed in the Vessel and return of the whole or part of the Equipment to the original place of manufacturer or supplier shall not be necessary in order to carry out any repair work Part VII Technical Specification Page 8 of 37 Supply of Two Units of Speed Boats for Marine Department Tender Ref Marine Department Shipbuilding Tender No 3 2015 Chapter 2 Technical Specifications 1 Introduction 1 1 1 2 1 3 1 5 1 6 1 7 1 8 1 9 1 10 Without prejudice to the generality of Chapter 1 this Chapter contains the more particular technical specifications for the Vessel The Vessel shall be equipped and fitted with all items specified in this Chapter 2 viz including all Equipment and fittings All such Equipment and fittings shall comply all specifications set out in this Cha
57. anguage k Others 1 Operating temperature m Relative humidity 36 3 1 2 Transceiver Flat panel colour LCD 12 inch or larger 640 x 480 pixels or better Head up Course up North up and True Bearing Modes with inputs of compass and speed data 0 125 nm to 36nm Selectable from nautical miles kilometres and kilo yards 30 m or better 1 5 or better of the maximum range of the scale in use or 30m whichever is the greater 1 5 degree or better English and desirably with Chinese With Adjustable electronic bearing lines and variable range markers features 150C to 550C or better 90 or better a Operating frequency 9410 30 MHz X band b Peak power output at least 4 KW c Pulse length equipped with long medium and short pulse modes for close medium and long range operation d Overall noise figure 6 dB or Better 36 3 1 3 Antenna a Operating frequency b Aerial Type c Horizontal beam width d Vertical Beam width e Sidelobes f Polarization g Rotation Speed h Operating temperature i Relative humidity 9410 30 MHz X band Radome radar antenna 24 or less 2 0 degrees or less 24 0 degrees or less Attenuated more than 23 dB within 10 the degrees of main beam and better than 30 dB outside 10 degrees of the main beam Horizontal Not less than 24 rpm within satisfactory operation at relative wind speed up to 70 knots Manual and automatic selection of antenna rotation speed f
58. arine Department Tender Ref Marine Department Shipbuilding Tender No 3 2015 impracticable for signal cables for datato be run inside conduits PVC insulated and sheathed with armoured cable shall be used d Equipment Fixing and Interconnection 36 1 1 d 1 All switches connectors jacks and receptacles shall be clearly logically and permanently marked during installation All wires and cables shall be identified at every termination and connection point with permanent type markers suitable for installation in the vessel 36 11 d 2 Interconnection of various items of equipment shall be mechanically and electrically connected by multi pin connectors or terminals 36 11 d 3 All cables shall be jointed by properly designed connectors or inside joint boxes Where terminal blocks are used for connection cables the tip of each conductor shall be crimped with a suitable terminal pin before it is inserted in to the terminal block 36 11 d 4 The Contractor shall be responsible for providing and installing properly rated power cables from the power points to his own equipment e Electricity 36 1 1 1 The power supply shall be compatible with vessel s DC electrical system 36 1 1 e 2 The equipment shall be protected by appropriately rated fuses The fuses shall be contained in independent fuse holders which are easily accessible f Cable 36 11 f 1 All exposed cables and wiring shall be sheathed or protected by metal conduits 36 1
59. arth TND 390 Jerba TND 289 Lamarsa TND 390 Tamerza TND 326 Others TND 289 Turkey Ankara TRY 735 Adana Incirlik TRY 605 Antalya TRY 646 Aydin TRY 603 Bursa TRY 594 Elmadag TRY 735 Gaziantep City TRY 523 Istanbul TRY 982 35 Amendment No 8 35 2015 Tender Ref Marine Department Shipbuilding Tender No 3 2015 Annex 4 10 First 28 nights Thereafter Country Currency City Izmir Cigli TRY 646 Manzarali TRY 735 All rates to be Nevsehir TRY 532 reduced by 10 Yamanlar TRY 646 for stay in any one Others TRY 461 city Turkmenistan Ashgabat TMT 735 Others TMT 470 Turks and Caicos Islands Turks and Caicos Islands USD 291 Tuvalu Tuvalu AUD 223 Uganda Kampala UGX 900 743 Entebbe UGX 535 147 Fort Portal UGX 466 267 Gulu UGX 291 417 Jinja UGX 765 632 Mbale UGX 386 790 Others UGX 291 417 Ukraine Kyiv UAH 4 838 Kharkiv UAH 3 195 Others UAH 3 066 United Arab Emirates Abu Dhabi AED 1 976 Dubai AED 2 013 Others AED 1 976 United Kingdom London GBP 332 Belfast GBP 233 Birmingham GBP 183 Bristol GBP 224 Cardiff Wales GBP 197 36 Amendment No 8 36 2015 Tender Ref Marine Department Shipbuilding Tender No 3 2015 Annez 4 10 First 28 nights Thereafter Country Currency City Caversham GBP 233 Cheltenham GBP 196 All rates to be Crawley GBP 332 reduced by 10 Edinburgh GBP 219 for stay in any one Gatwick GBP 229 it Glasgow GBP 195 a Harrogate GBP 145 High Wycombe GBP 191 Horley GB
60. ch shall provide and is capable of providing the Warranty Services for the Vessel during the Warranty Period 3 2 Notwithstanding and without prejudice to the Contractor s obligation to provide the Warranty Services Part VII Technical Specification Page 4 of 37 Supply of Two Units of Speed Boats for Marine Department Tender Ref Marine Department Shipbuilding Tender No 3 2015 for the Vessel under the Conditions of Contract the original copy of the manufacturer s warranty certificates and all related manuals and documents in respect of all the Eguipment valid for 12 months from the date of Acceptance Certificate of the Vessel shall be delivered to MD upon Delivery Acceptance 3 3 The full scope of the Warranty Services is more particularly set out in Annex to these TS 3 4 The Contractor is responsible for arranging the Vessel for Guarantee Slipping at the end of the 12 month Warranty Period In addition to any defects which the Contractor may be required to fix under Clause 18 of the Part IV Conditions of Contract the Contractor shall also be responsible for the rectification of any defects found in the course of Guarantee Slipping The full scope of the services to be provided as part of the Guarantee Slipping is more particularly set out in Annex 1 to these TS Acceptance and Delivery 4 1 Acceptance of the Vessel including all Equipment is to be carried out in two parts Part 1 Technical Acceptance Part 2 Delivery Accepta
61. clip and a shoulder carrying case The Contractor shall also supply a DC battery charger one for each vessel extra to the 220 Vac battery charger which can be readily and directly connected to a DC power outlet at each vessel such that the Portable Radio can be charged on the vessel if necessary The DC battery charger will normally be not in use and be stowed on the vessel with stowing space and facilities provided by the Contractor The following facilities shall be provided at the front panel of the equipment a PowerON OFF b Transmit indicator volume and squelch controls c Socket for plug for microphone and external speaker d Quick selection of Channel 16 e Channel selection and indicator f Dual watch mode selection g Transmission power selector for HIGH and LOW Power 25 W 1 W Performance Requirements i Transmitter Characteristics a Spurious and harmonics emissions 70 dB or better b RF Output Power 26W 1 W High Low il Receiver Characteristics a Sensitivity Less than 1 uV for 20 dB SINAD or equivalent Supply of Two Units of Speed Boats for Marine Department Page 28 of 37 Tender Ref Marine Department Shipbuilding Tender No 3 2015 iii b Adjacent Channel Selectivity 60 dB or better c Spurious Image Rejection 65 dB or better d Intermodulation 65 dB or better e Audio output Not less than 1 Watt at rated audio power output with less than 10 distortion Aerial and Fe
62. connection and reconnection 36 Requirements of Electronic Navigation Equipment ENE 36 1 Description of Electronic Navigation Equipment or alternatively referred to as communication and navigation equipment or ENE 36 1 1 36 1 2 36 1 3 36 1 4 36 1 5 36 1 6 36 1 7 36 1 8 In addition to the obligations of the Contractor as specified in this Part in relation to other Equipment and fitting as specified in this Part the Contractor is required to supply and is responsible for the supply delivery testing installation commissioning and warranty 12 months and provision of operational and maintenance service manual and training of the following electronic navigation equipment to be fitted on board the vessel for Marine Department MD a Echo Sounder and Depth indicator b Marine Daylight Viewing Colour Radar with Differential Global Positioning System and Electronic Chart System c Magnetic Compass and Flux gate Compass d International Maritime Mobile IMM VHF Radio with Global Maritime Distress Safety System GMDSS e Loudhailer and Siren System with USB player f Automatic Identification System AIS Receiver g Radar Reflector The Contractor shall provide all labour material transportation installation calibration testing and commissioning maintenance and support services in Warranty Period with the scope as specified in Annex to this Part and test equipment etc which are necessary
63. control unit which shall be completed with fist microphone and microphone hanger shall be recessed mounted in the wheelhouse with the following facilities provided at the front panel a Power ON OFF b Hail volume control c Function control Speech shall be delivered through a fist microphone hanging on the console The fist microphone shall be water proof The output power of the amplifier shall not be less than 30 watts and have the following characteristics a Hail sensitivity Better than 30 mV for 30 watts output at 1 kHz b Hail distortion Better than 10 at 30 watts output at 1 kHz The horn type loudspeaker shall be weatherproof reflex type 8 ohms impedance with power rating not less than 30 watts actual rating shall match with the amplifier 36 8 3 The positions of the master control unit of loudhailer siren system control panel shall be finalised in the detailed design stage 36 8 4 The system shall support playback of audio files stored at USB storage devices User friendly interface shall be provided to select start stop or pause the audio playback Part VII Technical Specification Supply of Two Units of Speed Boats for Marine Department Page 29 of 37 Tender Ref Marine Department Shipbuilding Tender No 3 2015 36 9 Automatic Identification System AIS Receiver 36 9 1 General Requirements a b c d The equipment shall receive navigation information from local AIS equipped vess
64. craft paints of the Regulation of Hong Kong Air Pollution Control Ordinance 8 3 Painting Schedule shall be submitted for MD approval before the Completion Date stipulated in Annex 6 to this part The proposal shall contain a list and the detailed specification of the paint intended to be used Thickness of each coating shall be specified 8 4 All painting work shall carry a one year guarantee provided by the Contractor against defects in material and workmanship The Contractor shall provide MD at Delivery Acceptance a letter of certification from the paint manufacturer to certify the application of the paint is under the paint manufacturer s quality control and in accordance to the manufacturer s requirements for the surface preparation control of the temperature of the metal surfaces amp atmospheric conditions paint thickness method of application etc 8 5 Tributyltin TBT free fouling release anti fouling paint shall be applied on the hull below water line for at least 2 years protection against the marine growth TBT free Certificate issued by the paint manufacturer shall be submitted before the Delivery Acceptance 8 6 All deck areas shall be covered with matt disruptive pattern multi tonal grey hard wearing and anti slip epoxy paint A Sample shall be submitted to MD for approval prior to painting 8 7 Outboard engine cowlings and foam collarettes shall be painted with matt disruptive pattern multi tonal grey The engine controls to b
65. ctor a notification of delivery date and location usually GD as stipulated in the contract SS GNC is to assign the Project Surveyors to take delivery of the vessel s One of the two Project Surveyors will be assigned as the Lead Project Surveyor to liaise with the Contractor SMM SSSM SFM if manned by MD crew and the User Department and to take delivery of the vessel s in accordance with the DAP If the delivery date is deemed not suitable e g due to approaching typhoon etc the Lead Project Surveyor is to seek the agreement of all concerned parties for an alternative delivery date and to inform SS GNC in a Minute stating the reasons for the delay The Lead Project Surveyor after consulting with the Project Surveyor SMM SSSM and SFM if manned by MD crew must ensure that a The vessel s will have safe access to the delivery location b The time of delivery is adequate for the purpose and convenient to all parties concerned c The Contractor fully understands and agrees with the procedures in the Delivery of the vessel and that the Contractor is fully aware of the PRP with respect to the payment at delivery d Safety in the delivery method of the vessel is acceptable if in doubt SFM s opinion should be obtained e GD has made the necessary arrangement to prevent unauthorized personnel to go onboard or near the vessel s at the time of taking delivery until the vessel is in the physical possession of the HKSAR Gov
66. cussed in the Kick Off Meeting 2 5 Installation of zinc anodes Mock up inspection of cabin console amp toilets also ee attended by two HPS officers 3 Equipment amp Outfitting Survey Details of the inspections have to be discussed in the Kick Off Meeting 3 1 Seats 3 2 Fenders 3 3 Petrol Tanks 3 4 Anchor and ropes 35 Tally Plates 3 6 Lightning Protection 3 7 Foldable Mast Part VII Technical Specifications Annex 6 Main Inspection Items Supply of Two Units of Speed Boats for Marine Department Page 1 of 3 Tender Ref Marine Department Shipbuilding Tender No 3 2015 3 8 Anti Slipping Arrangement 3 8 Air Conditioning System 4 Machinery Survey 4 1 Petrol Outboard Engines Commissioning Details of the inspections have to be discussed in the Kick Off Meeting 4 2 Propellers 4 3 Steering System Commissioning 4 4 Control and Instrumentation 5 Electrical Survey 5 1 DC Power Source Commissioning Details of the inspections have to be discussed in the Kick Off Meeting 5 2 Distribution Network 5 3 Cable Wiring and Fuse 54 Navigation and Search Lights 6 Electronic Navigational Eguipment Survey 6 1 Marine Daylight Viewing Colour Radar The acceptance tests for the electronic equipment systems shall comprise of three parts bench tests factory 6 2 Fluxgate Compass acceptance trials FAT and on site commissioning tests as required
67. d Plans and Drawings and they must consist of the following ones as well as any other additional ones that may be required by GNC MD during the design and construction of the Vessel and before the Vessel is accepted by the Government 1 2 The As Fitted Plans and Drawings shall be prepared by professional ship draughtsmen and they shall be prepared in a professional manner scale size and style normally required of in the ship design and construction business sector All plans and drawings shall show and be clearly marked for the profile plan and section views of the layout arrangement details and construction details in a manner required by GNC officer 1 2 1 General Arrangement Plan 1 2 2 Lines Plan and Offsets Data and table 1 2 3 Stability information booklet and the inclining experiment report 1 2 4 Hydrostatics Cross Curves and intact and damage stability calculations for all ship loading conditions specified in the Technical Specifications 1 2 5 Vessel Subdivision Drawings and stability calculations 1 2 6 Painting scheme of the whole vessel 1 2 7 Vessel draught marking diagram 1 2 8 Detailed Arrangement and Layout Plan of the Wheelhouse Cabins Decks showing the disposition of all main equipment fittings and fixtures furniture doors windows hatches manholes and access openings The Down Flooding openings points shall be clearing indicated on the drawings 1 2 9 Equipment layout diagram 1 2 10 Hull Struct
68. d in the Inclining Experiment Report The GM of the Vessel after each and every shift of inclining weights shall be determined Free surface of liquids remaining onboard shall be taken into account 2 5 This Inclining Experiment Report shall be submitted to MD for approval The report must include a statement from Contractor stating that the vessel should be safe to go to sea for the intended sea trials specified in the contract No sea trials should be conducted until GNC of MD agree based on the information given in the Inclining Experiment Report that it will be safe to carry out sea trials 3 Stability Information Booklet 3 1 The Contractor is to supply to MD three copies of Stability Information Booklet The Stability Information Booklet must be given to MD at time of Delivery Acceptance 3 2 The vessel shall comply with the stability criteria as mentioned in Section 4 and 5 of this Appendix In addition to the requirements stated above the booklet in its final version shall include a Vessel particulars sketch of general arrangement drawing showing different compartment and tank position hydrostatic curves and cross curves b Tank calibration sounding tables fuel oil tank fresh water tank etc These tables shall consist of locations of tanks frame numbers levels from tank bottom capacities VCG LCG TCG and free surface moments and location of sounding points The trim and heel of the vessel where these tables are applicable s
69. d maintenance of all the ENE specified in this paragraph 36 The trainer shall be able to communicate with the local trainees effectively c Itis anticipated that two distinct types of training shall be required namely a Operator Training b Equipment Maintenance Training d The Tenderer shall submit a detailed course syllabus a schedule for conducting the training course e For both types of training course each trainee shall receive one copy of the comprehensive training documents before the start of each course The Government shall have the right to reproduce all training documents for internal use f Training manual in Chinese and English shall be provided and submitted to MD and EMSD for approval at least one month prior to commencement of these two courses respectively g All training courses including all venue facilities materials and manuals shall be provided by the Contractor at no charge to the Government 36 14 2 Operator Training Course a This course is meant to be training for trainers Part VII Technical Specification Page 33 of 37 Supply of Two Units of Speed Boats for Marine Department Tender Ref Marine Department Shipbuilding Tender No 3 2015 b The course shall provide a full knowledge and appreciation of the day to day operation of all ENE specified in this paragraph 36 This shall include hands on demonstrations and operation of the eguipment including the necessary routine cleansing reg
70. due to the vessel s movements at maximum speed in the sea without damaging the integrity of the tanks 25 2 6 3 The fuel tanks shall have all fittings and openings on top except metallic fill and ventilation pipes which may be connected to the sides or ends of metal petrol fuel tanks provided that they are welded to the tank and reach above the top of the tank 25 2 6 4 Rigid fuel suction tubes and fill pipes which extend near the tank bottom shall have sufficient clearance to prevent contact with the bottom during normal operation of the craft 25 2 6 5 An inspection manhole air vent with flame trap on deck and discharge valve with remote operated quick closing device shall be provided Part VII Technical Specification Page 16 of 37 Supply of Two Units of Speed Boats for Marine Department Tender Ref Marine Department Shipbuilding Tender No 3 2015 25 2 6 6 The tanks support chocks or hangers shall either be separated from the surface of metal tanks by non metallic non hygroscopic non abrasive material or welded to the tank 25 2 6 7 An easily removable coarse strainer shall be built into the filling line 25 2 6 8 Baffles shall be provided the total open area provided in the baffles shall be not greater than 30 of the tank cross section in the plane of the baffle 25 2 6 9 Baffle openings shall be designed so that they do not prevent the fuel flow across the bottom or trap vapour across the top of the tank 25 2 6 10 The tank
71. e 24 7 Components in the system shall be externally protected against corrosion The complete hydraulic steering system shall be designed to withstand conditions of pressure vibration shock and movement without failure or leakage 24 8 Hydraulic systems shall be capable of operation throughout an ambient temperature range of 10 C to 60 c and be capable of withstanding storage at 30 OC to 60 C 24 9 Materials used in hydraulic steering systems shall be resistant to deterioration by liquids or compounds with which the material may come in contact under normal marine service e g grease lubricating oil hydraulic fluid common bilge solvents salt and fresh water 24 10 The type of hydraulic fluid to be used in a hydraulic steering system shall be specified by the manufacturer of the steering system and shall be stated in the owner s manual The hydraulic fluid shall be non flammable or have a flash point of 157 C or over 24 11 Hydraulic lines shall be supported by clips straps or other means to prevent chafing or vibration damage The clips straps or other devices shall be corrosion resistant and shall be designed to prevent cutting abrading or damage to the lines and shall be compatible with hydraulic line materials 24 12 A flexible section shall be installed between rigid piping and cylinder s 24 13 The steering wheel is to be fitted with an anti slip covering 24 14 The piping shall comply with one of the international standard
72. e etc with valid cable connections for fault finding and equipment testing These extended cables shall be properly managed and resided inside the console 36 11 a 10 Induced mutual interference for a number of equipment shall be within an acceptable level b Installation Location 36 11 b 1 Installation location shall be easily accessible for inspection and maintenance Exact location shall be subjected to the approval of the Government 36 11 b 2 Installed location of equipment shall not cause interference to other equipment by way of the emittedinterference c Material and Workmanship 36 1 1 c 1 Material and equipment shall be of high quality and shall comply with where applicable the appropriate British Standards and Code of Practice together with any amendments made thereto suitable for installation in the vessel 36 11 c 2 All works shall be carried out in a first class workman like manner and shall be subjected to the approval of the Government 36 1 1 c 3 The Government reserves the right to reject any part of the installation not comply to the Specification The Contractor shall carry out the necessary remedial work or replacement without extra cost or delay 36 11 c 4 The Contractor shall provide all installation materials including cables casing mounting accessories and etc which are durable and fire retarding Where it is Part VII Technical Specification Page 31 of 37 Supply of Two Units of Speed Boats for M
73. e all travelling and Government Officers allowances based on Annez 12 Government Subsistence Allowance Rate The Tenderer shall propose the survey visits for the Main Inspection Items in Schedule 10 and estimate the expenses allowed that deemed to have been included in the Total Contract Price in Schedule 1 Duration and the number of visits shall enable the representatives to conduct the survey visit in accordance with the Contract 6 Official Sea Trial and Speed Requirements 6 1 The Contractor shall submit for MD approval an Official Sea Trial programme which shall include details of proposed procedures for carrying out the Official Speed Trial manoeuvring test planning tests crash stop test endurance test anchor test and inclining experiment This programme must be submitted to MD in not less than 14 working days before the trials commence 6 2 Like all other tests and trials to be conducted as part of the Technical Acceptance the Contractor is required to carry out the Official Sea Trial at its own expense including the expense of petrol lubrication oil crew and other necessary expenses in the presence of MD officer s 6 3 The Contractor shall provide a trial report to GNC after completion of the above tests The report shall contain information regarding method of test sea weather and wind conditions Vessel loading condition heel angle during turn for forward turning with engine running and any other relevant information and
74. e delivered for the Delivery Acceptance The Government will not accept delivery if after undergoing the tests and trials in the Technical Acceptance the Government does not consider that the Vessel is in Ready to Use condition Survey and Inspection 5 1 Tenderers shall note that the unit price per Vessel quoted in the Schedule 1 Price Schedule in Part V shall be deemed to have included the cost of surveys to be carried out by the relevant Recognised Organisations in respect of that Vessel if required to be arranged by the Contractor under the Contract and survey visits by GNC inspectors and surveyors and the representatives of the user department 5 2 The Tenderers shall state the regulations or rules from which of the Recognised Organisation or other Organization acceptable by MD based on which the proposed Vessel will be designed and built 5 3 All electronic items and their installations shall be approved and inspected by EMSD as part of the Technical Acceptance 54 Subject to paragraph 5 6 of this Chapter 1 an advanced written notice of not less than 5 working days if the Vessel is located in China including Hong Kong and 10 working days if the Vessel is located in any other part of the world must be given to GNC before the representatives of GNC and representatives of the user department are invited to conduct a survey visit of the Vessel The Contractor shall be fully responsible for any delay if the Contractor fails to give adequa
75. e electric wires for the fuel oil tank level sensor s no other should pass through any fuel tank compartment s Ventilation for the fuel tank compartment s shall comply with national or other acceptable industrial standards 25 2 3 The total capacity of the tank shall be not less than 700 litres The unpumpable capacity of the each tank shall not be more than 10 of the capacity of that tank It is preferable to have both of the tanks containing the same capacity of petrol 25 24 All seals such as gaskets O rings and joint rings shall be of non wicking i e non fuel absorbent material All materials used shall be resistant to deterioration by the fuel for which the system is designed and to other liquids or compounds with which the material can come in contact as installed under normal operating conditions e g grease lubricating oil bilge solvents and sea water 25 2 5 Internal surfaces of the petrol tank shall be left unpainted and the petrol tank internal shall be cleaned thoroughly to the satisfaction of MD 25 2 6 Provisions to the Petrol Tanks 25 2 6 1 A tank content gauge and low level alarm shall be fitted on the control console for each tank A sounding rod calibrated in litres shall be supplied for each tank 25 2 6 2 Marine grade stainless steel 316 with increased resistance to corrosion shall be used The thickness shall sustain the loads due to the mass of the full tank with due consideration given to upward and downward acceleration
76. e of a non reflective grey matt paint 9 General Arrangement 9 1 Whilst the Contractor is required to exercise its professional expertise and knowledge to come up with an appropriate design for the Vessel which can comply with all requirements of the Contract a General Arrangement Plan is attached at Annex 3 to Technical Specifications for guidance purposes Part VII Technical Specification Page 11 of 37 Supply of Two Units of Speed Boats for Marine Department Tender Ref Marine Department Shipbuilding Tender No 3 2015 9 2 The Vessel shall be designed to accommodate 6 officers The layout drawing shall be submitted in dwg file to the satisfaction of MD 10 Deck Cabin 10 1 10 2 10 3 10 5 10 6 Deck cabin includes console seating space and toilet Deck cabin design shall keep maz air draught 2 95m Forward hinged door shall match cabin shape 5 seats shall properly be arranged in cabin the space provided shall be plan equipped with microwave amp a small refrigerator size not less than height 510 x width 440 x depth 470 mm And a foldable table fitted for report writing and meeting An air conditioner A C shall be installed for cabin Genset for A C and storage shall be arranged on rear of boat Design Collapsible equipment tower or folding tower to keep max air draught 2 95m Following shall be fitted in cabin 10 6 1 One electric powered marine wall clock 10 6 2 One swing type metal rubbish bin with cover
77. eas where water may accumulate or at least 25 mm above the level at which the automatic bilge pump switch activates The metallic sheathing armour or braid of cable shall be properly earthed at both ends All bare terminals shall be properly insulated by approved cable insulators Wiring shall run along conduits with watertight openings and be secured in such a manner as to allow easy maintenance Suitable watertight cable glands shall be provided at the openings of watertight compartment or deck penetrations Overcurrent Protection 29 5 1 29 5 2 A manually reset trip free circuit breaker or a fuse shall be installed within 200 mm of the source of power for each circuit or conductor of the system or if impractical each conductor shall be contained within a protective covering such as a sheathing conduit or cable trunking for its entire length from the source of power to the circuit breaker or fuse The voltage rating of each fuse or circuit breaker shall not be less than the nominal circuit voltage the Part VII Technical Specification Page 20 of 37 Supply of Two Units of Speed Boats for Marine Department Tender Ref Marine Department Shipbuilding Tender No 3 2015 29 6 29 7 29 8 29 9 current rating shall not exceed the value for the conductor of smallest diameter in the circuit 29 5 3 Output circuits of self limiting generators and battery chargers do not require fuses or circuit breakers Switchboard 29
78. echnical Acceptance shall be delivered at the Contractor s expense to the Government Dockyard If either of the Vessels or both of them together with all Equipment and other Deliverables cannot be delivered to the Government Dockyard in Ready for Use condition by the Delivery Date specified in Schedule 2 and that the delay lasts for more than 120 days the Government has the power to reject the delayed Vessel s or both Vessels and the Equipment and other Deliverables relating to the delayed Vessel s or all Equipment and other Deliverables and the Contract may be terminated according to the applicable terms stipulated in the Contract including Clause 13 of the Conditions of Contract 4 3 2 On delivery the Vessel must be in Ready for Use clean tidy and fully fitted and operational condition 4 3 3 The Contractor must demonstrate to MD that all machinery electrical and electronic equipment are in good working order and must hand over the Vessel its fixtures and equipment to MD in good and complete condition 4 3 4 The Delivery Acceptance of the Vessel shall be carried out by GNC in accordance with the terms stipulated in the Contract including Conditions of Contract this Part and Annex 9 to this Part The Delivery Acceptance is only completed when the Acceptance Certificate is issued by the Director of Marine 4 3 5 Not later than six weeks before the Delivery Acceptance of the Vessel the Contractor is required to submit to GNC four cop
79. ection and repair within 24 hours excluding Hong Kong public holidays of receiving the report of a fault fault report and to take immediate action of rectifying the defect after inspection Unless otherwise agreed by the Government all corrective maintenance and rectification must be effected within 48 hours after the fault report is first issued MD must be informed of what the corrective maintenance and rectification actions have been taken within 72 hours of receiving the relevant fault report 1 7 2 To provide all necessary transport replacements Equipment spare parts labour and materials tools and testing instruments required for the corrective maintenance and rectification 1 7 3 Any replacement item or part to be used shall be originated from the manufacturer of the original Warranty Item to be repaired and can be found in latest spare parts list issued by such manufacturer Alternative components shall not be used without prior approval in writing of MD If the Contractor fails to respond to any reported warranty claims within 48 hours MD may arrange defect corrective maintenance and rectification either on its own or by deploying another third party contractor as deemed appropriate with a view to minimizing any downtime incurred In such case the Contractor shall compensate the Government for the full cost of such repairs plus 10 as and for liquidated damages but not as a penalty no later than 10 working days after a written demand
80. eder a The aerial provided shall be marine type aerial with at least 3 dBi gain vertically polarized omni directional and suitable for mounting on the launch b The V S W R of the aerial installed shall be less than 1 5 1 c The aerial feeder shall be RG58U type or equivalent d Coaxial cable lightning suppresser with appropriate earthing connection shall be provided for protecting the radio equipment All outdoor connector joint should be properly covered by waterproof tape or material 36 8 Loudhailer Siren with USB player 36 8 1 The system shall function as a loudhailer siren system for external broadcast specially designed for maritime purposes 36 8 2 Loudhailer Siren 36 8 2 1 36 8 2 2 36 8 2 3 36 8 2 4 36 8 2 5 36 8 2 6 36 8 2 7 The system shall comprise a master control unit in wheelhouse and two weather proof horn type loudspeakers in conformance to IPX5 or better located at forward and aftward of the vessel respectively It shall have the capacity to generate a Yelp siren and a horn signal sound in manual mode It shall also has a selection of at least 6 warning signal sounds in automatic mode for general marine navigational uses namely Underway Stopped Sail Tow Anchored and Aground There shall be a volume control on external broadcasting speakers so they shall be adjustable to full power for messages to be heard 0 5 km away and down to minimum for night operations The master
81. eller ventilation so that there is no loss of directional control 2 Performance Tests Conditions at Performance Tests 1 Person Onboard 6 Persons 2 Deadweight 75 kg x 6 500 kg 3 Fuel Petrol 40 50 of Fuel Tank 4 Other Equipment 100 kg 5 Sea Conditions wind speed below 11 knots 6 Others All the machinery and equipment as required in the Technical Specifications shall be fully installed onboard 3 Manoeuvrability Tests Conditions at Manoeuvrability Tests Sea Conditions wind speed below 11 knots Others 1 Person Onboard As per above requirements 2 Deadweight As per above requirements 3 Fuel Petrol As per above requirements 4 Other Equipment 100 kg 5 6 All the machinery and equipment as required in the Technical Specifications shall be fully installed onboard 4 Crash Stop Tests Conditions at Crash Stop Tests Sea Conditions wind speed below 11 knots Others 1 Person Onboard 6 Persons 2 Deadweight 75 kg x 6 500 kg 3 Fuel Petrol 40 50 of Fuel Tank 4 Other Equipment 100 kg 5 6 All the machinery and equipment as required in the Technical Specifications shall be fully installed onboard Part VII Technical Specifications Annex 8 Sea Trial Conditions Page 1 of 2 Tender Ref Marine Department Shipbuilding Tender No 3 2015 5 Astern Running Test
82. els The equipment shall be a AIS receiver which is able to receive both Class A and Class B AIS information The AIS receiver shall be able to receive AIS information to and from AIS equipped vessel nearby such as dynamic data vessel position coordinated universal time UTC course over ground COG speed over ground SOG rate of turn ROT heading static data maritime mobile service identity MMSI vessel names type of ship call signs length and beam heading destination latitude and longitude location of position fixing antenna on the ship short safety related messages and other navigation data from vessel nearby The AIS receiver supplied shall be equipped with interface connecting to display including the display of the radar system The AIS shall allow the radar display AIS information given by the AIS receiver 36 9 2 Performance Requirements 36 9 2 1 36 9 2 2 36 10 Radar Reflector Receiver Characteristic a Frequency range 161 975 MHz and 162 025 MHz b Channel interval 25kHz c Receiver sensitivity 105dBm or better d Dual parallel channel receiver Aerial and Feeder a The aerial provided shall be marine type aerial with at least 3 dBi gain vertically polarized omni directional and suitable for mounting on the launch b The V S W R of the aerial installed shall be less than 1 5 1 c The aerial feeder shall be RG58U type or equivalent Coaxial cable lightning suppresser with app
83. ender for the Contract all plans and drawings of the Vessel except the design stresses and scantling shall be submitted to GNC for approval before completion of the Vessel design 2 3 The design stresses and scantling including internal structural members shall be determined in according to the rules of Recognised Organisation All designed drawings shall be approved by Recognised Organisation before submitting to MD for comment 2 4 The Contractor shall design build and supply the Vessel in full compliance with the requirements given in these TS which to that extent may be over and above that is normally required by any statutory and Recognised Organisation s rules 2 3 If any contradiction between the rules and regulations of an RO and the TS the final decision shall be made by the GNC authority 2 6 Even if the Contractor may appoint a Sub contractor to design the Vessel with the prior written consent of the Government the Contractor shall not be relieved of its obligations under the Contract through such appointment and the Contractor shall be responsible for all acts defaults and omissions of the sub contractor as if they were its own 3 Warranty Services During the Warranty Period 3 1 The Contractor is required to be a Government Dockyard Contractors Item HI Hull Deck amp Tailshaft Group II or has entered into a binding sub contract with a Government Dockyard Contractors Item IH Hull Deck amp Tailshaft Group II whi
84. ent extension in relation to any Warranty Item under the terms of the Contract 2 2 At the Guarantee Slipping the Contractor shall carry out the following work and provide all necessary materials spare parts labour and equipment in order to carry out such work 2 2 1 Electrical and Mechanical Items if applicable 2 2 1 1 Main Engine and Gearbox a Replace engine s and gearbox s lubrication oil and lubrication oil filters b Replace all engine petrol filters c Change clean all engine air filter elements 2 2 1 2 All the belts of generator engines to be checked and adjusted if necessary a Renew all zinc anodes in cooling water passage of coolers b Adjust belts of engine and replace any deteriorated belts as found c Adjust all engine inlet and exhaust valves clearances d Check and test for correct operation of all engine instrumentation gauges and sensors Repair replace any defective components e Functional tests of all engine gearbox protection system and associated sensor switches Repair replace any defective components f Strip down all engine starters and charge alternators for inspection Renew all bearings Clean up and Megger test all windings Check for correct operation of all components Carry out repairs or parts replacement if found necessary Reassemble all items in good working condition g Run up and check for normal operation of all engine gearbox Conduct sea trials afterwards Performance and tri
85. equipment schematic diagram in English language at least 2 original giving full details on the following in respect of each piece of ENE as specified in this paragraph 36 at no charge to the Government a Operations and working principals b Equipment functional description c Equipment specifications d Schematic block diagrams and circuit diagrams with sufficient information and details for equipment maintenance and repairing e Calibration procedures f Equipment adjustment mounting procedure and parameter settings g Part list with part numbers and locations the adjustment calibration tools kit program shall also include h Maintenance and troubleshooting instructions i Equipment interfacing with wiring diagram with clear signal labelling j Software operation manual for equipment driven by application software k As fitted conduit trunking route diagrams for the electronic equipment installed onboard for the purpose of future maintenance are to be submitted 1 The design conduit trunking route diagrams are to be submitted to MD and EMSD for approval during construction stage 36 14 Training on Electronics Navigation Equipment specified in this paragraph 36 36 14 1 General requirements a All training courses shall be held in the HKSAR b The Contractor shall provide appropriate classroom as well as on board training to the operational and technical staff to familiarise officers with the operation an
86. ernment and under the control of SFM or the user department f Specific requirements if any from SFM SMM SSSM and the User Department with respect to the method of Acceptance have been duly conveyed to the Contractor in good time well before delivery and accepted by the Contractor Lead Project Surveyor is to ensure all parties concerned understand the contractual obligation of the Contractor as far as Delivery is concerned and g If for any reason any concerned parties wish to trial run the vessel during Delivery the express consent in writing from the Contractor with respect to safety crew method and area of the sea trial etc must be obtained in advance before the delivery date Both the Lead Project Surveyor and Project Surveyor are to check the Inventory List provided by the Contractor for its completeness in accordance with the contract requirements All comments received from SFM SSSM and the User Department must be duly noted down in writing and presented in the Minute report see below Upon taking physical possession of the vessel s and the vessel s is under the safekeeping of GD the Lead Project Surveyor is to prepare a Minute report to SS GNC which will include the following details a Date time and location of the Delivery b References to all signed documents and Inventory List c Name and duty of each person presented in the Acceptance d Outstanding items if any and e Any other matters that should
87. face to accept and display navigation data such as latitude and longitude positions of the vessel given by the GPS DGPS receiver 36 3 1 5 The Contractor shall pay special attention to any possible radar blind zone and address this during the design stage and verify it after installation and rectify it if required Special attention shall be paid to the equipment installed before the radar scanner like flood lights and or horn speakers Care shall also be taken to ensure the mounting does not obstruct the navigation lights 36 3 1 6 The radar shall have standard NMEA 0183 interface ports i e National Marine Electronics Association NMEA Standard capable of accepting navigational data from a wide selection of GPS DGPS Receivers Electronic Compasses and to output comprehensive data on all tracked targets in the form of a track table to a wide selection of electronic chart plotters However connection of the radar system to the other systems supplied under this Contract via other standard interface types equivalent to NMEA 0183 is acceptable 36 3 1 7 The power of the equipment shall be supplied from the D C 24V system of the vessel 36 3 1 8 The radar transceiver shall be housed in a radome antenna scanner unit of maritime type It shall be designed for aloft mounted construction and capable of satisfactory operation at relative wind speeds of not less than 70 knots 36 3 1 9 Guard zones and alarm functions shall be provided in the radar The zo
88. for approval 14 Lockers Void Spaces 14 1 Lockers Lockers or storage spaces shall be provided 15 Seating and Attachment Systems 15 1 15 2 15 3 15 5 Three shock absorption heavy duty dampers seats with turntable 0 to 180 degree adjustable seat height fore and aft adjustment 160mm adjustable back rest foot step and inertia reel three point seat belt shall be provided at the aft of Console for the coxswain and commander Four shock absorption heavy duty dampers seats shall be provided for 4 officers The Seats shall be designed to protect the operator from injury and optimize the body posture to mitigate the potentially harmful forces that occur during the Vessel in operations as specified in paragraph 4 and the operational profile as specified in paragraph 6 of this Chapter 2 Such as Mechanical suspension with 2 double acting hydraulic damper Seating and arm rests shall provide with support for spinal neutral alignment and postural stability for each person up to the crew limit and also to prevent them from falling or being thrown on deck or overboard Such as inertia reel three point seat belt Basic Requirements of the Seats 15 5 1 Material of the Structure Steel and or Aluminum Alloy 15 5 2 Materials of Upholstery Seat cushions back rests and settees shall be Reinforced Nylon Laminated Neoprene PVC 15 5 3 Seats with the safety belts the tension thrust should be able to withstand no less than 2
89. for the Vessel shall be provided as per the requirements set out in Annex 11 to this part 35 Tally Plates 35 1 Builder Plate A builder s plate shall be fitted The following information but not limited to shall be displayed on each builder s plate a Manufacturer s name and b Maximum number of persons that the craft is designed to carry while underway 35 2 Tally plates in both English and Chinese characters shall be fitted for spaces and equipment at the following locations 35 2 1 Equipment in the console 35 2 2 Electrical and communication equipment 35 2 3 Air vents and filling pipes for the petrol tank 35 2 4 All valves 35 2 5 Control panels switchboards distribution boxes and electrical circuits 35 2 6 Any other equipment fittings as required Part VII Technical Specification Page 22 of 37 Supply of Two Units of Speed Boats for Marine Department Tender Ref Marine Department Shipbuilding Tender No 3 2015 35 3 35 4 35 5 35 2 7 Information engraved on tally plates shall include a source of power fuse rating voltage and warning and b Any other information as required Tally plates exposed to weather shall be made of durable and non corrosive material and be securely fastened A tally plate specifying the maximum number of crew and passengers to be carried on board shall be displayed at a prominent position on the main deck All cable termination shall be clearly identified for dis
90. foresaid conditions the Government will deem that the Vessel has failed to pass the Official Speed Trial and therefore Technical Acceptance The Government may reject the Vessel and terminate the Contract or exercise such other options as specified in Clause 12 of the Conditions of Contract and other applicable provisions of the Contract 6 4 6 The instrument use in measuring the Contract Speed for the Official Speed Trial is to be provided either by 6 4 6 1 The Contractor provided that the speed measuring device has been calibrated by a certified body acceptable by MD or 6 4 6 2 Stopwatch or 6 4 6 3 Global Positioning System GPS supplied by the Government 6 4 7 The Vessel must be in the trial conditions see Annex 8 to these Technical Specifications for the conditions of the trials during the Official Speed Trial All equipment shall also be in operation during the trial 6 4 8 The speed time of the day engine running conditions sea condition etc shall be properly recorded by the Contractor and signed as witnessed by GNC surveyor or their representatives during the trial A copy of the report shall be given to GNC before Delivery Acceptance 6 5 Endurance and Performance Test The Endurance and Performance Tests for the engine s load speed against the Vessel s Speed fuel consumption with engine s operating parameters shall be conducted and the testing results shall be recorded as per the requirements stipulated in Annex 13
91. g devices power stabilizer or regulator shall be provided and installed at no extra cost if required 36 1 1 a 5 RF connectors of suitable impedance shall be provided and used for connections of the RF cables antennae and radio equipment Connectors between the feeder cables and antennae shall be protected by weatherproof material to avoid water seepage 36 11 a 6 All wiring shall be finished in a neat and approved manner 36 1 1 a 7 Adequate measures to prevent interference between the electronic equipment shall be taken which include a Separate screened conduits or trunkings shall be provided b Rules regulations and recommended practices regarding screening of electric wiring must be observed c Receiving apparatus and other electronic equipment which may be affected by radio frequency induced voltages must be effectively earthed screened and protected against such voltages d Lightning protection devices shall be fitted 36 11 a 8 All sitting installation and cabling work shall be undertaken to the highest standard to ensure a Satisfactory performance of the equipment b Protection from mechanical and water damages c Ease of accessibility for maintenance and repair d Manufacturers recommendations are to be strictly observed 36 11 a 9 The power signal and control cables connecting to the flush mounted equipment shall be long enough to let the equipment wholly place on a safe place like on the panel tabl
92. g Velocity 999 kt or better Differential Beacon Receiver a Frequency range 283 5 325 kHz b Frequency Step 500 Hz c Position Accuracy Smor better Environmental requirements a Temperature Operating temperature 15 to 55 b Water resistance splash proof 36 5 Electronic Chart System ECS 36 5 1 Generalrequirements Part VII Technical Specification Page 26 of 37 Supply of Two Units of Speed Boats for Marine Department Tender Ref Marine Department Shipbuilding Tender No 3 2015 36 5 1 1 A PC which can display Electronic Navigational Chart ENC data compiled under International Hydrographic Organization IHO Transfer Standard for Digital Hydrographic Data Standard Version 3 1 An ENC software Orac Master G2 must be installed in the PC DGPS receiver transmit the NMEA data to the PC by connecting DGPS and PC through communication port e g COM Ports USB etc 36 5 1 2 A display unit of size not less than 430mm diagonal high resolution colour LCD 36 5 1 3 A keyboard and a mouse capable of input data and operate the ENC 36 5 1 4 Capable of display chart track waypoints and navigation data 36 5 2 Specific requirements 36 5 2 1 PC with the following requirements a Operatingsystem Window 7 Professional Chinese or above b CPU Intel Core i5 or better c RAM 4 GB d Display card Up to 1920 x 1080 HDMI DVI interface e DVDROM 30x f HDD SSD g HD 128GB or above h Software Microsoft
93. hall be stated c Stability calculation for each loading condition shall include a profile drawing items of deadweight light vessel displacement drafts trim VCG GM solid amp fluid LCG down flooding angle statistical stability curve etc d Any other information as reasonably required by MD and e Inclining experiment report approved by MD 3 3 In the preliminary and final stability calculation the estimated and the final obtained after conducting an Inclining Experiment light vessel data shall be used respectively Both the preliminary and final Stability Information Booklet shall include the following loading conditions and any other conditions as may be required by MD during the construction of the vessel Loading Conditions Fuel Oil Fresh Water Crew amp Effects Kg 1 Lightship Nil Nil Nil 2 Full Load Departure Condition i e 98 100 510 Trial Condition Part VII Technical Specifications Annex 2 Stability Requirement Page 1 of 2 Supply of Two 2 Speedboats for MD Tender Ref Marine Department Shipbuilding Tender No 3 2015 The maximum free surface moments shall be used in calculating the stability of the vessel in all of the above conditions Weight of each crew and passenger is assumed to be 75kg and effect per person to be 10 kg VCG of each crew officer will be assumed as 750mm above deck LCG of each crew officer will be in their most likely position onboard T
94. he vessel should be capable to operate safely at No 3 typhoon signal hoisted situation in Hong Kong Intact Stability Criteria 4 1 Stability will be considered satisfactory if the following criteria are complied with after taking free surface effects into account for lightship and loaded conditions as specified above a b c d e ii The maximum righting lever GZ occurs at angle of heel of not less than 25 degrees The righting lever GZ should be at least 200mm at an angle of heel equal or greater than 30 degrees The area under GZ curve should not be less than i 0 055 metre radian up to an angle of 30 degrees angle of heel ii 0 090 metre radian up to an angle of 40 degrees angle of heel or an angle at which the lower edges of any openings in the hull superstructures or deckhouses being openings which cannot be closed weathertight are immersed if that angle be less iii 0 030 metre radian between the angle of heel of 30 and 40 degrees or such lesser angle as is referred to in ii above The initial transverse metacentric height after correction of the free surface effects should not be less than 0 15 metre In the worst service condition the angle of heel due to the effect of either crowding of passengers or turning the vessel should not be greater than 10 degrees or 80 of angle of deck edge immersion whichever is less The effects should be determined as follows Crowding of passengers the passenge
95. hnical Specifications Annex 11 Markings and Colour Scheme Page of 1 Supply of Two Units of Speed Boats for Marine Department Tender Ref Marine Department Shipbuilding Tender No 3 2015 Annex 12 Government Subsistence Allowance Rate w e f 1 4 2015 Part VII Annex 12 Supply of Two Units of Speed Boats for Marine Department Tender Ref Marine Department Shipbuilding Tender No 3 2015 March 2015 Annez 4 10 Rates of subsistence allowance outside Hong Kong w e f 1 4 2015 First 28 nights Thereafter Country Currency City Afghanistan Kabul AFN 11 528 All rates to be Others AFN 5 764 reduced by 10 Albania for stay in any one Tirana ALL 31 563 city Others ALL 14 951 Algeria Algiers DZD 30 073 Others DZD 21 243 Andorra Andorra EUR 263 Angola Luanda AOA 56 539 Others AOA 56 539 Anguilla Anguilla XCD 622 Antarctica Antarctica Region Posts USD 1 Antigua and Barbuda Antigua and Barbuda XCD 746 Others XCD 162 Argentina Buenos Aires ARS 2 886 Bariloche ARS 2 785 Mendoza ARS 2 422 Others ARS 2 464 Armenia Yerevan AMD 97 819 Others AMD 97 819 Ascension Island Ascension Island SHP 26 1 Amendment No 8 1 2015 Tender Ref Marine Department Shipbuilding Tender No 3 2015 Annez 4 10 First 28 nights Thereafter Country Currency City Australia Canberra AUD 418 All rates to be Adelaide AUD 443 reduced by 10 Brisbane AUD 384 for stay in any one Broome AUD 492 city Cairns A
96. ies of the Inventory List covering all items of or relating to the Vessel including all engines on board equipments manuals documentation spares stores Equipment for testing in respect of the entire Vessel The Inventory List shall need to be approved by MD before the day of Delivery Acceptance and covers everything which the Contractor is required to deliver under the Contract At the Delivery Acceptance of the Vessel the approved Inventory List will be used to check Part VII Technical Specification Page 5 of 37 Supply of Two Units of Speed Boats for Marine Department Tender Ref Marine Department Shipbuilding Tender No 3 2015 that all the items have been delivered to MD in a satisfactory state Details of each inventory item shall include item name description type quantity manufacture s name manufacturer s part reference number and or serial number and the items location in the Vessel 4 3 6 The items specified in paragraph 38 of Chapter 2 and all items set out in the Inventory List in the form as approved or stipulated by the Government shall be delivered to MD at the Delivery Acceptance of the Vessel Delivery Acceptance will follow GNC s Delivery Acceptance Procedures as set out in Annex 9 or otherwise as stipulated by the Government The Contractor must provide 14 days advance notice in writing for Vessel delivery when the Vessel is considered to be completed in accordance with the Contract and Ready for Use and to b
97. iginal Paint in Vessel s name draft marks and insignia two coats Scrape disc sand wire brush clean wash and paint all deck surfaces Apply two touch up coats deck primer and one full coat non slip deck paint to all decks Scrape wire brush clean and apply two touch up coat primer one touch up and one full finishing coat to deckhouse and all deck fittings including mast rails stanchions hatches etc All varnish work to sand down smooth clean and re varnish two coats Slightly sand down between coats Free clean grease and recondition all moving parts of the deck fittings i e WT hatches vent covers roller and fairleads and anchor chain stopper etc 2 2 3 Dock Trial Sea Trials after Guarantee Slipping To demonstrate proper functioning and operation of the following before and during sea trials after Vessel s warranty slipping 2 2 3 1 Before Sea Trial a Outboard engine control and steering system b Outboard engine alarm and shut down function including emergency stopping of engines c Navigational equipment light and sound signal d Other trials as recommended and required 2 2 3 2 At Sea Trial a Engine performance trial b Ahead and astern running and crash stop test c Steering trial d Other trials as recommended and required Part VII Technical Specifications Annex 1 Warranty Services and Guarantee Slipping Page 4 of 4 Supply of Two 2 Speedboats for Marine Department Tender Ref Marine De
98. in machineries and electrical equipment The list shall include 38 2 3 1 Description 38 2 3 2 Type model 38 2 3 3 Makers part no or equivalent 38 2 3 4 Location 38 2 3 5 Quantity 38 2 3 6 Supplier or agents name and contact address 38 2 3 7 Order time 38 2 3 8 Shelf life 38 2 3 9 Unit cost Part VII Technical Specification Page 35 of 37 Supply of Two Units of Speed Boats for Marine Department Tender Ref Marine Department Shipbuilding Tender No 3 2015 38 24 38 2 5 38 2 6 38 2 7 38 2 8 4 copies at least 1 original of maker operation maintenance and workshop manuals for all machineries equipment in English 4 copies of Docking Plan which shall include the profile plan and sections shall be prepared by the Contractor 4 copies of Onboard Operator s Manual English and Chinese covering 38 2 6 1 Daily user check and operation procedure 38 2 6 2 Operating detail of each system 38 2 6 3 Emergency operation procedure The precise format and detail required will have to be subject to the Government s approval when the configuration of the Vessel and outfitting is decided The first draft of the Onboard Operator s Manual both English and Chinese shall be submitted to MD for approval ONE month before documentation acceptance The documentation for all Equipment spares and stores special tools and test equipment shall be provided at the Delivery Acceptance of the Vessel 3
99. ine Department Tender Ref Marine Department Shipbuilding Tender No 3 2015 29 3 alarms if individually protected by a circuit breaker or fuse as close as practical to the battery terminal Distribution Network 29 3 1 12 24V DC services shall be supplied from the switchboard in the steering console through a 2 wire insulated system to the following items a Navigation light control panel and navigation lights b Horn c General lighting d Compass light e Instrument panel in control console f Content gauge for petrol tank g Submersible bilge pump h One hand held searchlight and one fixed searchlight i Siren G Blue flashing light k Any other navigational and electronic equipment if applicable 29 4 Conductors 29 5 29 4 1 29 4 2 29 4 3 29 4 4 29 4 5 29 4 6 29 4 7 29 4 8 29 4 9 29 4 10 29 4 11 29 4 12 Conductor insulation shall be of fire retardant material e g not supporting combustion in the absence of flame Conductors that are not sheathed shall be supported throughout their length in conduits cable trunking or trays or by individual supports at maximum intervals of 300 mm Sheathed conductors and battery conductors to the battery disconnect switch shall be supported at maximum intervals of 300 mm with the first support not more than 1 m from the terminal Other sheathed conductors shall be supported at maximum intervals of 450 mm Sheathed engi
100. isplay 36 6 2 The fluxgate compass shall consist of at least a sensor unit and a display unit and be compact and easy to operate It shall have direct connection to the radar 36 6 3 An electronic display unit shall be installed at a position for easy viewing of vessel heading by the coxswain Digital display is preferred 36 6 4 The fluxgate compass shall be electronic design which GPS DGPS will not cause deviation 36 6 5 The fluxgate compass shall be provided to allow the operation of the radar in north stabilized mode and supply heading direction information to colour plotter system 36 6 6 Performance Requirements of fluxgate compass a Reference Either Magnetic North or True North Part VII Technical Specification Page 27 of 37 Supply of Two Units of Speed Boats for Marine Department Tender Ref Marine Department Shipbuilding Tender No 3 2015 b Accuracy 1 0 typical or better c Resolution 0 1 or better d Deviation Compensation Automatic e Operating Temperatures OC to 50 f Waterproofing IPX5 36 7 International Maritime Mobile IMM VHF Radio with GMDSS 36 7 1 General Requirements 36 7 1 1 36 7 1 2 36 7 1 3 36 7 1 4 36 7 1 5 36 7 1 6 36 7 1 7 36 7 1 8 36 7 1 9 36 7 1 10 36 7 1 11 36 7 1 12 Part VII Technical Specification The IMM VHF radio shall be a type approved make by The Office of Communication Authority of Hong Kong The Radio shall be fully c
101. ka ZMW 1 783 Livingstone ZMW 2 121 Others ZMW 1 095 Zimbabwe Harare USD 334 Bulawayo USD 212 44 Amendment No 8 44 2015 Tender Ref Marine Department Shipbuilding Tender No 3 2015 Annex 4 10 First 28 nights Thereafter Country Currency City Victoria Falls USD 411 Others USD 177 All rates to be Other Foreign Localities reduced by 10 Other Foreign Localities USD 55 for stay in any one city Note Hotel accommodation related taxes are not included in the rates of subsistence allowance for the destinations in the United States of America USA Hotel accommodation related taxes paid during duty visits in the USA should be reimbursed on an actual expenses basis under CSR 714 1 if they are paid for by the officer concerned 45 Amendment No 8 45 2015 Tender Ref Marine Department Shipbuilding Tender No 3 2015 Part VII Annex 13 Endurance and Performance Test Du of Test Place of Test Vessel s Identification Vessel s Name Conditions at Endurance and Performance Test 6 Persons Dummy Weight Fuel Diesel 75 of Endurance Range Capacity Other Equipment 100 kg Sea Conditions Calm sea with wind speed below 6 knots maximum wave height of less than 0 5 m Sea Water Depth not less than 5 meters Maker Maker Type Type Serial Number Diameter Rated Power Pitch Rated Speed Direction of Engine Load __ of rated Power
102. ks along wind direction needed to walk against the gale 28 33 knot 13 19 ft Moderate amounts of airborne wind 13 9 17 1 m s spray 62 74 km h 17 2 20 6 m s 55 7 5m Moderately high waves with B a breaking crests forming spindrift Some twigs broken from trees Gale 39 46 mph 8 fresh aje Well marked streaks of foam are Cars veer on road Progress gt 34 40 knot 18 25 ft blown along wind direction on foot is seriously impeded 17 2 20 7 m s Considerable airborne spray 75 88 km h 20 8 24 4 m s 7 10 High waves whose crests Some branches break off 47 54 mph m sometimes roll over Dense foam is trees and some small trees 9 Strong gale blown along wind direction Large blow over 41 47 knot 23 32 ft amounts of airborne spray may Construction temporary signs 20 8 24 4 m s begin to reduce visibility and barricades blow over 10 Storm 89 102 km h 24 7 28 3 m s 9 12 5m Very high waves with overhanging Trees are broken off or Part VII Technical Specifications Annex 10 Definitions of Wave and Page 1 of 2 Tender Ref Marine Department Shipbuilding Tender No 3 2015 whole gale 55_63 mph crests Large patches of foam from uprooted saplings bent and wave crests give the sea a white deformed Poorly attached 48 55 knot appearance Considerable tumbling asphalt shingles and shingles 29 41 ft of waves with heavy impact Large in poor condition peel off 24 5 28 4 m s amounts
103. l be borne by the Contractor Total Vessel Warrant It is required that the Vessel is covered by free of charge Warranty Services for one year after the date of Acceptance Certificate in respect of the Vessel The Warranty Services shall cover the entire Vessel and all its Equipment including engines and electronic equipment fittings and outfit including spare parts and documentation collectively Warranty Items against defects of design construction workmanship or materials and against any non compliance with any of the Product Warranties The Warranty Services may be backed up by the Contractor using individual equipment suppliers manufacturers warranties but the Contractor shall remain solely liable to MD as a primary obligor to provide the Warranty Services Notwithstanding and without prejudice to the Contract on warranty obligations for the total Vessel any individual equipment supplier manufacturers warranty extending beyond the one year total Vessel warranty must be assigned to the Government as appropriate Procedures for Warranty Claim Without prejudice to the provisions of the Contract a detailed procedure for dealing with warranty claims must be proposed by the Contractor and agreed to by MD before the issuance of the Acceptance Certificate of the Vessel This shall be based on the following principles 1 6 1 Any notification of claimed defect to be sent from MD to the Contractor or the GRSS appointed Part VII Tech
104. le 20 Lightning Protection Arrangement 21 List of Spare Parts 22 Others Note All the drawings are required to submit in one month after Signing of Articles of Agreement for GNC approval reference Details of the submission have to be discussed in the Kick Off Meeting Supply of Two 2 Speedboats for Marine Department Part VII Technical Specifications Annex 5 Implementation Timetable Drawing Submission Page 1 of 1 Tender Ref Marine Department Shipbuilding Tender No 3 2015 Part VII Annex 6 Implementation Main Inspection Items Item No Items to be Inspected Completion Date for the Main Inspection Items Item1 ist vessel Item 2 2nd vessel 1 Painting Application 1 1 Painting Schedule Paint Schedule is required to submit in one month after the Contract Date for Vessel Item 1 and 2 1 2 Hull Surface Finishing Inspection Details of the inspections have to be discussed in the Kick Off Meeting 1 3 Ist Coating Inspection 1 4 2nd Coating Inspection if applicable 1 5 Final Coating Inspection 2 Hull amp Cabin Survey 2 1 Documents Checking Hull materials certificates Mill Cert Welding materials WPR PQR Welder s certificates 2 2 Stage 1 Fit up Details of the inspections have to be discussed in the Kick Off Meeting 2 3 Stage 2 Weld Final Inspection 2 4 Non Destructive Tests NDT Locations of the NDT to be dis
105. n delivery 31 4 The Vessel shall be fitted with a proven lightning protection system to protect the personnel onboard and the electronic equipment installed Method and working principle of protection shall be submitted for MD approval before the Completion Date stipulated in Annex 6 to this part 32 Search Lights 32 1 Sockets for one 100W portable search lights shall be installed at the specified location Also one flood light at aft of cabin and one fixed search light adjustable by person within the wheelhouse shall be provided on top of cabin 33 Life saving Appliances and Fire fighting Equipment 33 1 The life saving appliances and fire fighting equipment shall comply with IMO Standards Minimum requirements refer to Local Vessel Ordinance of HKSARG 33 2 Life saving Appliances 33 2 1 6 lifejackets and one children lifejacket and 33 2 2 One lifebuoy with buoyant life line in length of 30m Two additional lifebuoy shall be supplied for rescue usage 33 3 Fire fighting Equipment 33 3 1 Two 4 5 kg dry powder fire extinguisher shall be provided with holding rack 33 3 2 One 9 litre foam fire extinguisher shall be provided with holding rack and 33 3 3 One manual fire pump with fire main hose hydrant jet spray nozzle shall be provided with holding rack including a sea suction cock situated outside the engine room 33 4 A safety plan shall be provided onboard in wheel house 34 Markings and Colour Scheme 34 1 Markings and colour scheme
106. nce 4 2 Technical Acceptance 4 2 1 This includes all the technical mechanical and electrical tests and trials as required in this Part and those considered necessary by the Government including equipment tests anchoring tests stability test and bottom survey on the slipway in the HKSAR the Official Speed Trial as mentioned in paragraph 6 4 of this Chapter 1 the Endurance and Performance Test as mentioned in the paragraph 6 5 Manoeuvrability Test as mentioned in the paragraph 6 6 Crash Stop Test as mentioned in paragraph 6 7 and other tests as mentioned in paragraph 6 8 and 6 9 of this Chapter 1 the on site commissioning tests for the ENE as mentioned in paragraph 36 of Chapter 2 of this Part and all other verification tests to determine whether or not the Vessel including the Equipment has been supplied in accordance with the all specifications set out in these Technical Specifications excluding only the Excluded Specifications 4 2 2 The Contractor shall pay for all material and labour costs for carrying out the tests and trials stated in sub paragraph 4 2 1 of this Chapter 1 4 2 3 If the Vessel still cannot pass all of the tests comprised in the Technical Acceptance by the Delivery Date specified in the Contract the options available to the Government are set out in Clause 12 of the Conditions of Contract and other applicable provisions of the Contract 4 3 Delivery Acceptance 4 3 1 The Vessel after its successful completion of T
107. nding on the unit s water pressure A long run alarm for the pump shall be fitted at the wheelhouse The relief valve setting if fitted and the pressure testing of the freshwater tank shall be conducted in the presence of a GNC officer 26 6 Detailed specifications of the pressurised unit including manufacturers catalogue shall be submitted for MD approval 27 Generator Set 27 1 One 220V AC single phase marine diesel driven generating set of proprietory make with sound shield shall be installed underdeck Detection system for fire or gas in generator compartment is to be provided 27 2 The output power of the generator set shall be sufficient to meet ship s loading requirement for air conditioning plus 20 reserve margin 27 3 The generator set shall be DC battery started attenuator to be drip proof construction and its starting stopping and on loading shall be by manual means 27 4 Normal shore supply voltages on the Vessel are 220V for essential electric apparatus One 220V single phase power supply to the electric equipment from the distribution board shall be through circuit breakers The distribution system for 220V AC shall be 2 wires insulated 28 Air conditioning System 28 1 Air conditioning with adequate back up ventilation shall be provided for the wheelhouse compartment to maintain comfort when operating in heavy spray and in a high temperature high humidity summer 28 2 The air conditioned space temperature shall be 24 C
108. ne Boise USD 165 city Others USD 165 Illinois Springfield USD 183 Chicago USD 317 Others USD 183 Indiana Indianapolis USD 201 Others USD 201 Iowa Des Moines USD 190 Others USD 190 Kansas Topeka USD 165 Others USD 165 Kentucky Frankfort USD 165 Lexington USD 200 Louisville USD 220 Others USD 165 Louisiana Baton Rouge USD 190 Others USD 190 Maine Augusta USD 165 Others USD 165 Maryland Annapolis USD 220 Baltimore USD 275 Others USD 220 39 Amendment No 8 39 2015 Tender Ref Marine Department Shipbuilding Tender No 3 2015 Annex 4 10 First 28 nights Thereafter Country Currency City Massachusetts Boston USD 371 All rates to be Marlborough USD 252 reduced by 10 Others USD 371 for stay in any one Michigan city Lansing USD 181 Detroit USD 212 Others USD 181 Minnesota St Paul USD 264 Minneapolis USD 264 Rochester USD 211 Others USD 264 Mississippi Jackson USD 165 Others USD 165 Missouri Jefferson City USD 165 Guam USD 165 Others USD 165 Montana Helena USD 183 Big Sky USD 202 Others USD 183 Nebraska Lincoln USD 165 Omaha USD 207 Others USD 165 Nevada Carson City USD 185 Clark County USD 208 Las Vegas USD 208 Others USD 185 40 Amendment No 8 40 2015 Tender Ref Marine Department Shipbuilding Tender No 3 2015 Annez 4 10 First 28 nights Thereafter Country Currency City New Hampshire Concord USD 177 All rates to be Othe
109. ne can be set and shown on the display screen Audible alarm shall be activated if other vessels enter the zones set 36 3 1 10 The display unit shall be of table top mounting type providing clear and clutter free picture in all weather conditions and suitable for bright daylight and night viewing It shall indicate clearly the important parameters such as radar targets range marker bearing line heading marker range rings guard zone and background etc Part VII Technical Specification Page 24 of 37 Supply of Two Units of Speed Boats for Marine Department Tender Ref Marine Department Shipbuilding Tender No 3 2015 36 3 1 11 a Power ON OFF b Standby Transmit On the viewing side of the display unit the following controls shall be provided c Automatic adjustment of gain sea clutter and tune keeps targets clearly in view d True motion display the vessel s movements relative to fixed targets e Bearing cursor rotation f Variable range marker g Range scale selection h Display brilliance amp illumination i Selection of background colour and target colour j Tuning k Heading marker ON OFF 36 3 1 Performance Requirements The marine radar shall perform at least the following requirements 36 3 1 1 Display Unit a Display b Screen size c Resolution d Display mode e Range scale f Range units g Minimum range h Range ring accuracy i Radar bearing accuracy j Display l
110. ne starter conductors constitute an exception to this requirement Conductors which may be exposed to physical damage shall be protected by sheaths conduits or other equivalent means Conductors passing through bulkheads or structural members shall be protected against damage to insulation by chafing Conductors shall have minimum dimensions in accordance with IEEE or other equivalent international standard acceptance to MD or the conductor manufacturer s rated current carrying capacity based on the load to be supplied and allowable voltage drop for the load to be carried Conductors in voltage critical circuits such as starter motor circuits and navigation light circuits whose output may vary with system voltage shall be sized in compliance with the component manufacturer s requirements Each conductor longer than 200 mm installed separately shall have an area of at least 1 mm2 Each conductor in a multi conductor sheath shall have an area of at least 0 75 mm and may extend out of the sheath a distance not to exceeding 800 mm An exception may be made for conductors of minimum area 0 75 mm which may be used as internal wiring in panel boards Each electrical conductor that is part of the electrical system shall have a means to identify its function in the system except for conductors integral with engines as suppled by their manufacturers Current carrying conductors shall be routed above anticipated levels of bilge water and in other ar
111. ng the construction of the Vessel 5 6 After arriving at the site for a survey visit if the MD Government officer considers it is unsafe to carry out the test or inspection the test inspection will not be carried out The Contractor shall have to arrange another additional survey visit at the Contractor s own expense The Government shall not be responsible for any delay arising from any delay in conducting the survey visit due any safety issue as specified in this paragraph 5 7 Where any fee charge and associated expense are payable for the services of a Recognised Organisations which services are necessary in order to fulfil any obligation of the Contractor under the Contract the Contractor is responsible to pay the Recognised Organisations all such fees charges and the associated expenses Such fees shall include charges for drawing approval surveys if deemed necessary issues of certificates and any other expenses payable to the Recognised Organisations 5 8 If the Vessel is built in any part of the world outside the HKSAR the Contractor is required to arrange and pay the Government all expenses incurred by the Government for arranging the staff of MD Part VII Technical Specification Page 6 of 37 Supply of Two Units of Speed Boats for Marine Department Tender Ref Marine Department Shipbuilding Tender No 3 2015 and user department officers to carry out survey visits construction progress visits to the Vessel which shall includ
112. ngine maker showing that the design and workmanship power output of the engine installation is suitable for the application service profile of the Vessel and up to his satisfaction 23 Propellers 23 1 All propellers are to be of stainless steel with fixed pitch Removable propeller shrouds are to be provided for propellers but not be fitted during the Official Speed Trial 24 Steering System 24 1 The Vessel shall be fitted with a hydraulic steering system approve by the engine s manufacturer as evidenced by a confirmation to be issued by the engine s manufacturer 24 2 The hydraulic steering system shall be designed with two hydraulic cylinders operating in parallel The steering capability must be maintained with one cylinder malfunctioned If the oil supply to the hydraulic steering system fails or too small the steering unit shall be able to work in an emergency manual steering mode 24 3 A redundant system with independent power supply shall be provided to maintain the vessel steering capability in case of main power supply failure 24 4 The hydraulic oil tank shall be located that ready access is available for level checking 24 5 Outboard engines shall be designed so that with any combination of engine turn and tilt there shall be no damaging interference between the motor its accessories and both the craft mounted and the engine mounted system 24 6 Connections fittings oil fill openings and air bleeders shall be accessibl
113. nical Specifications Annex 1 Warranty Services and Guarantee Slipping Page 1 of 4 Supply of Two 2 Speedboats for Marine Department Tender Ref Marine Department Shipbuilding Tender No 3 2015 by it through a defined route 1 6 2There shall be a joint inspection to examine the defect and the Contractor shall propose the appropriate and necessary remedial action to satisfaction of MD 1 6 3 The Contractor shall undertake on site Warranty Services including provision of all replacement Warranty Item spare parts labour materials test equipment and transportation wherever at the option of the Government the Vessel is berthed in Government Dockyard or maintenance bases of the user department Taking the Vessel to the shipyard of the Contractor or of the GRSS appointed by it should be avoided unless absolutely necessary 1 6 4 Rectification of defect must have minimum effect on operation of Vessel by provision of on loan equipment when the anticipated repair time exceeds the time frame as specified in paragraph 1 7 1 below 1 7 Throughout the Warranty Period the Contractor shall be responsible for the provision of free of charge corrective maintenance and rectification of all defects in all and any of the Warranty Items including repair and replacement as necessary This shall at no cost to MD include Warranty Services to be performed by the Contractor described in the following sub paragraphs 1 7 1 To attend to the Vessel for insp
114. ntilles Curacao ANG 549 Aruba ANG 603 Bonaire ANG 394 Saba ANG 538 Sint Maarten Dutch Part ANG 542 Others ANG 394 26 Amendment No 8 26 2015 Tender Ref Marine Department Shipbuilding Tender No 3 2015 Annez 4 10 First 28 nights Thereafter Country Currency City New Caledonia New Caledonia XPF 27 361 All rates to be New Zealand reduced by 10 Wellington NZD 434 for stay in any one Auckland NZD 450 city Christchurch NZD 396 Queenstown NZD 344 Rotarua NZD 339 Others NZD 328 Nicaragua Managua NIO 6 222 Corn Island NIO 4 732 San Juan del Sur NIO 8 157 Others NIO 4 000 Niger Niamey XOF 104 572 Others XOF 81 161 Nigeria Abuja NGN 93 420 Bauchi NGN 48 919 Calabar NGN 37 793 Enugu NGN 40 248 Ibadan NGN 25 850 Jos NGN 40 084 Kaduna NGN 61 844 Kano NGN 54 481 Lagos NGN 66 588 Maiduguri NGN 30 431 Port Harcourt NGN 64 462 Sokoto NGN 27 650 Warri NGN 38 448 Yenagoa NGN 36 975 Others NGN 30 431 27 Amendment No 8 27 2015 Tender Ref Marine Department Shipbuilding Tender No 3 2015 Annex 4 10 First 28 nights Thereafter Country Currency City Niue Niue NZD 189 All rates to be Norway reduced by 10 Oslo NOK 2 384 for stay in any one Stavanger NOK 2 268 city Others NOK 2 384 Oman Muscat OMR 160 Salalah OMR 111 Others OMR 111 Pakistan Islamabad PKR 31 870 Faisalabad PKR 18 343 Karachi PKR 31 767 Lahore PKR 35 149 Peshawar PKR 20 597 Quetta PKR 22 237 Other
115. ochabamba BOB 925 reduced by 10 Santa Cruz BOB 1 415 for stay in any one Others BOB 766 city Bosnia Herzegovina Sarajevo BAM 299 Others BAM 299 Botswana Gaborone BWP 1 897 Francistown BWP 1 823 Kasane BWP 2 128 Selebi Phikwe BWP 1 555 Others BWP 1 971 Brazil Brasilia BRL 858 Belem BRL 718 Belo Horizonte BRL 642 Fortaleza BRL 794 Foz do Iguacu BRL 503 Goiania BRL 797 Manaus BRL 596 Natal BRL 721 Porto Alegre BRL 708 Porto Velho BRL 576 Recife Pernambuco BRL 716 Rio de Janeiro BRL 1 270 Salvador da Bahia BRL 789 Sao Paulo BRL 1 047 Others BRL 753 Brunei Bandar Seri Begawan BND 370 Jerudong BND 447 Others BND 157 AA Amendment No 8 4 2015 Tender Ref Marine Department Shipbuilding Tender No 3 2015 Annez 4 10 First 28 nights Thereafter Country Currency City Bulgaria Sofia BGN 420 All rates to be Bourgas BGN 205 reduced by 10 Plovdiv BGN 352 for stay in any one Varna BGN 240 city Others BGN 234 Burkina Faso Ouagadougou XOF 134 227 Bobo Dioulasso XOF 78 559 Others XOF 78 559 Burma Rangoon MMK 343 559 Naypyitaw MMK 252 471 Others MMK 315 836 Burundi Bujumbura BIF 289 374 Others BIF 289 374 Cabo Verde Praia CVE 23 938 Boa Vista Island CVE 21 327 Fogo CVE 13 405 Sal Island CVE 25 070 Sao Tiago Island CVE 9 662 Sao Vicente Island CVE 19 673 Others CVE 10 881 Cambodia Phnom Penh KHR 963 564 Siem Reap KHR 992 145 Sihanoukville KHR 620 601 Others KHR 347 047 Cameroon Yaounde
116. of airborne spray reduce roofs visibility 103 117 km h 28 6 f ji 32 5 m s 11 5 16m Exceptionally high waves Very Widespread damage to i large patches of foam driven vegetation Many roofing 1 Violent 64 73 mph before the wind cover much of the surfaces are damaged asphalt storm sea surface Very large amounts of tiles that have curled up 26 63 knot airborne spray severely reduce and or fractured due to age 28 532 6 mis 37 52 ft visibility may break away completely 2 118 km h 2 32 8 m s Very widespread damage to 214m Huge waves Sea is completely vegetation Some windows 274 mph we ae ae may break mobile homes and white with foam and spray Air is 12 Hurricane filled with driving spray reall poorly constructed sheds and 264 knot E SRE aJs SAEY barns are damaged Debris 2 46 ft reducing visibility and unsecured objects are 2 32 7 m s hurled about World Meteorological Organization WMO Sea State Code Sea State Code Wave Height meters Characteristics 0 0 Calm glassy 1 0 to 0 1 Calm rippled 2 0 1 to 0 5 Smooth wavelets 3 0 5 to 1 25 Slight 4 1 25 to 2 5 Moderate 5 2 5 to 4 Rough 6 4to6 Very rough 7 6t09 High 8 9to 14 Very high 9 Over 14 Phenomenal Character of the Sea Swell 0 None Low 1 Short or average 2 Long Moderate 3 Short 4 Average 5 Long Heavy 6 Short 7 Average 8 Long 9 Confused Part VII Technical Specifications Annex
117. ofile as specified in paragraphs 4 and 5 of this Chapter 2 respectively The maximum permanent list of the Vessel shall not be greater than one degree The Vessel shall be free of unacceptable structural vibrations and excessive porpoising at all speeds so that there is no loss of directional control Berthing requirements of the Vessel shall match with the designated points of berthing at the Government Dockyard and HPS Operational Base 2 Rules and Regulations 2 1 The Vessel and all related works shall be in compliance with the requirements of the various regulatory bodies and rules listed below that are in force at the time of Contract signing insofar as they may apply 2 1 1 Relevant Rules and Regulations applicable to this type of vessel for the construction of hull and machinery from one of the Recognized Organisations by HKSARG 2 1 2 International Regulations for Preventing Collisions at Sea 1972 as amended by IMO resolution A 464 XII and A 626 XV 2 1 3 International Electro technical Commission IEC Regulations for the Electrical and Electronic Equipment 2 1 4 International Telecommunications Union recommendations in the International Radio Regulations ITU R 2 1 5 Quality and standards of the weldings shall comply with the rules of a Recognised Organisation or American Welding Society AWS or other applicable international standards or rules acceptable to MD 2 1 6 The Vessel and other Deliveries shall be designed and man
118. ol spark ignition engines of adequate power for the Contract Speed The engines shall drive stainless steel fixed pitch propellers through the integral gearboxes 21 2 The Contractor shall be responsible for ensuring the correct installation and setting up of the engines including the choice of propellers so as to avoid ventilation and cavitations 21 3 The declared rated power of an engine model or propulsion system shall be the full throttle power at the declared rated speed at the final output shaft of the engine or propulsion system as offered for sale by the manufacturer The power measurements and declarations for the engines and the propulsion system shall comply with the requirements in accordance with International Council of Marine Industry Associations ICOMIA 28 83 21 4 The emission of the engines shall comply with 3 Stars Ultra Low Emission or higher required by California Air Research Board CARB star system that describes exhaust emissions of both two stroke and four stroke outboard engines or equivalent E 21 5 Each of the engines shall be controlled by one set of throttle forward reverse lever The two levers will be conveniently placed for one handed simultaneous operation by the coxswain 21 6 The Engine Throttle Control Head shall be provided on the right hand side of the steering wheel 21 7 The engines shall be equipped with power trim And a switch at the helm that enables the operator to adjust the trim angle on the fl
119. ompatible to Global Maritime Distress Safety System GMDSS and equipped with a lithium battery of lifetime at least 5 years The Radio shall be fully compatible to Global Maritime Distress Safety System GMDSS which is a class A Digital Selective Calling DSC transceiver fully compatible with the International Maritime Organization IMO GMDSS carriage requirements The equipment shall be equipped with all the entire international maritime VHF channels complete with a fist microphone with press to talk switch or telephone handset mic handset hanger mounting bracket and loud speaker The equipment shall incorporate with Channel 12 and shall be able to dual watch on Channel 16 or one of the other channels The equipment shall complete with antenna and integrated microphone loudspeaker control knobs keys display screen etc necessary for a stand alone portable radio The equipment shall complete with antenna and battery The operating temperature shall be 0 C to 55 C The water ingress protection shall be IPX5 or better The radio supplied shall complete with antenna and re chargeable battery 220 Vac battery charger for battery charging on shore and one extra set of spare re chargeable battery The Contractor shall provide proper stowing space and facilities for keeping of the Portable Radio and the spare battery such that the crew can take the Portable Radio out for use when necessary The equipment shall be supplied with a belt
120. on leaflets literature manuals and booklets etc and whatsoever items that are necessary for the operation handling services maintenance spare parts repairs and the technical understanding of any one of all the engines machinery motors pumps equipment fittings and outfitting items of the Vessel Part VII Technical Specifications Annex 14 Page 2 of 2 Supply of Two Units of Speed Boats for Marine Department Tender Ref Marine Department Shipbuilding Tender No 3 2015 Part VII Appendix A Conceptual Block Diagram of Electronic Equipment Siren and External Broadcast System Siren and External Broadcast System GPS DGPS Receiver Radar System with 12 inch Display Electronic Navigational AIS Receiver Chart Radio Fluxgate Antenna Radar Echo Compass Reflector Sounder Sensor GPS and DGPSAntenna Fluxgate Compass Display 8 AIS Antenna Marine Band VHF Transceiver Part VII Technical Specifications Appendix A Page 1 of 1 Supply of Two Units of Speed Boats for Marine Department
121. ooring or alongside other vessels The fender shall be tightly fixed to the hull and flush on the highest deck level The collar must be clear of the water when planning with full load and at rest with full fuel and no payload onboard The fender is to have excellent resistance to impact abrasion and to hot and cold climate extremes and will not be affected by petrol diesel lubricating oil or chemicals Part VII Technical Specification Page 13 of 37 Supply of Two Units of Speed Boats for Marine Department Tender Ref Marine Department Shipbuilding Tender No 3 2015 17 6 The outer diameter of the fender shall be around 350mm The bow section shall be comparatively larger than 350mm in order to suit bow on boarding Details of the design dimensions and arrangement drawing of the fender shall be submitted to MD for approval prior to construction 17 7 Provision for attachments of four 4 portable fenders at Port and Starboard side of vessel and four 4 portable fenders are to be provided The manufacturer s certificate shall be provided for approval 18 Bow The bow shall be reinforced to withstand frequent boarding operations Two forwards doors shall be provided on port and starboard side of hull The design drawing shall be provided to MD for approval 19 Transom and Stern Area 19 1 A tray with drains shall be attached to fore of the transom to accommodate the petrol filters control wires and hydraulic steering pipes 19
122. or example 24rpm 36rpm 48rpm shall be available according to detection range 15 C to 55 C or better 90 or better 36 3 1 4 Heading Marker Bearing Measurement and Display a This thickness of heading marker shall not be greater than 0 5 degree with an accuracy better than 1 degree Part VII Technical Specification Page 25 of 37 Supply of Two Units of Speed Boats for Marine Department Tender Ref Marine Department Shipbuilding Tender No 3 2015 36 3 1 5 b Arrangements shall be provided for bearing measurement with an accuracy of better than 1 5 degree Bearing discrimination shall be better than 2 0 degrees ARPA Automatic Radar Plotting Aid Requirement a Target Acquisition 10 targets or better manual b Tracking Automatic c ARPA Range Scales From 0 75 to 12 nautical miles or better d Readout of Selected Target Range bearing course speed CPA Closest Point of Approach TCPA Time to Closest Point of Approach d Target Vector Relative true e Intercept Mode Automatically calculate intercept course and Time to Go TTG to tracked target 36 3 2 The crew operator shall be able to select the following modes of presentation at the radar display a radar image only b plotter image only c plotter image overlaid with radar image 36 4 DGPS receiver 36 4 1 36 4 2 General requirements 36 4 1 1 36 4 1 2 36 4 1 3 36 4 1 4 The information received by the GP
123. ounding the device when an ignition source causes an internal explosion or 25 1 4 2 It is incapable of releasing sufficient electrical or thermal energy to ignite a hydrocarbon mixture or 25 1 4 3 The source of ignition is hermetically sealed 25 1 5 The only outlets for drawing fuel from the fuel system shall be the plugs in petrol filter bowls intended solely for the purpose of servicing the filter 25 1 6 In any fuel filling system each metal or metal plated component which may come into contact with fuel shall be grounded to earth with a maximum resistance of 1 Q 25 1 7 Grounding wires shall not be clamped between a hose and its pipe or spud 25 1 8 Fuel filling systems shall be designed to avoid blowback of fuel through the fill fitting when filling at a rate of 30 litres min at between 1 4 and 3 4 full of the tank capacity 25 2 Petrol Tank 25 2 1 One stainless steel petrol tank shall be mounted at under deck position The tank shall not be integral with the hull and shall be installed so that the loads due to the mass of the full tank are safely induced into the structure with due consideration given to upward and downward acceleration due to the vessel s movements at maximum speed in the sea In this respect continuous flexible supports spreading loads are preferable to rigid ones The design and tests shall comply with the requirements of Recognised Organisation or other international standards acceptable to MD 25 2 2 Except th
124. partment Shipbuilding Tender No 3 2015 Part VII Annex 2 Stability Requirement 1 General All calculations and drawings must be in metric units The calculations can be carried out by using a proven viz recognized by a government authority or classification society computer program If a computer program is used the user manual input and output format must first be acceptable to MD The submitted output data must be accompanied with input data 2 Inclining Experience 2 1 An inclining experiment is to be carried out with the attendance of a MD officer 2 2 The Contractor shall submit at least 14 working days in advance a Scheme of Inclining Experiment which includes a The Vessel s intended condition of the vessel during the Inclining Experiment with intact stability results b The proposed locations and movements of inclining weights c The calculation of estimated heel and trim of vessel before and during the experiment d The proposed number location and lengths of pendulum used and e The list of data to be measured i e draughts specific gravity of floating water etc 2 3 The Inclining Experiment shall only be conducted a After the Scheme of Inclining Experiment has been approved by MD officers and b In the presence of MD officer s Request for attendance should be made at least five working days in advance 2 4 The lightship weight and centres of gravity shall be calculated and presente
125. pply of Two Units of Speed Boats for Marine Department Tender Ref Marine Department Shipbuilding Tender No 3 2015 The test shall be carried out during Technical Acceptance b The Contractor shall arrange to submit test reports on the performance of the eguipment and deliver the test reports and eguipment to the Electrical and Mechanical Services Department s EMSD representatives for bench acceptance test prior to the installation of the equipment on the Vessel c The Contractor shall submit schedule of on site commissioning test of the electronic equipment installed onboard at least one month prior to the commissioning test date d The Contractor shall provide all the necessary test equipment and tools for carrying out the commissioning test and acceptance test at no extra cost 36 13 Documentation amp Quotation For the Proposed ENE 36 13 1 The Tenderer shall supply with its tender the following documentation a Technical and proposed equipment information including integrated system equipment schematic diagram of all these general electronic equipment in English sufficiently detailed to enable a technical appraisal of the equipment in this Chapter to be made b Tenderers shall list the electronic equipment required in this paragraph 36 with unit price in Schedule 1 36 13 2 The Contractor shall upon delivery of the Vessel to the Government Dockyard supply three sets of Operation Manual Service Manual and integrated system
126. pter 2 as well as those specified in the tender then submitted by the Contractor including product information and literature supplied by the Contractor for these items The significance of Essential Requirements and Criteria for Technical Assessment are explained in paragraphs 1 3 and 1 4 of Chapter 1 above Whilst the Contractor is required to exercise its professional expertise and knowledge to come up with an appropriate design for the Vessel which can comply with all requirements of the Contract a Guidance General Arrangement Plan is attached at Annex 3 to these TS for guidance purposes The Vessel shall be designed for navigation in waters up to and including Beaufort scale 6 and sea state 5 and used within the operating temperature of 20 C to 60 C Principal Features Length Overall 9 10 metres E Max Breadth Not more than 4 2 metres E Max Mean Draught not more than 0 7 metre E Max Air Draught 2 95 metre E Material of Hull Structure Aluminium Alloy E Hull form Catamaran E Contract Speed 35 knots at the engine declared rated power with the Vessel under Official Speed Trial Conditions as stated in Annex 8 to this Part The Vessel shall be designed to accommodate 2 crews and 4 officers All of them shall be provided with the dampened seats as stipulated in paragraph 15 of Chapter 2 to this part E The general arrangement shall enhance the effective operation of the Vessel based on its usage and operational pr
127. raining course shall accommodate the specified number of traine Part VII Technical Specification Page 34 of 37 Supply of Two Units of Speed Boats for Marine Department Tender Ref Marine Department Shipbuilding Tender No 3 2015 37 Services Support 37 1 General Philosophy 37 1 1 In determining the appropriate design for the Vessel all of the following factors shall equally be taken into account without one outweighing another 37 1 1 1 Vessel performance e g engine rating size etc 37 1 1 2 Initial cost 37 1 1 3 On going cost e g maintenance cost petrol consumption spare parts etc 37 1 1 4 Reliability frequency and time to repair breakdown 37 1 1 5 Time between maintenance periods 37 1 1 6 Time to undertake scheduled maintenance downtime 37 1 2 Allowable Vessel downtime including scheduled preventive maintenance and unscheduled repair and maintenance shall not exceed 10 of the total hours of operation per month based on the operation profile as specified in paragraph 5 of this Chapter The Tenderer shall propose a model of main engines with the necessary rating and power for the Vessel to enable compliance with this performance service level Frequency of overhaul for the engine shall be consistent with the allowable Vessel downtime 37 2 Maintainability the Vessel shall be easy to maintain by ensuring that there shall be 37 2 1 Good access to all installed items for monitoring service and overhaul 37 2
128. raining purposes The price shall be INCLUDED from the Total Purchase Price of the Vessel in the Schedule 1 E 39 Training for Handling and Maintenance of the Vessel 39 1 In addition to the training to be provided for the ENE the Contractor shall provide training in relation to the handling of the Vessel for the operational staff of the user department training in relation to maintenance of engine and equipment onboard for the maintenance staff of the user department and for the Maintenance Section of Government Dockyard 39 2 In order to ensure the navigational work up team of the HPS acquire full knowledge and appreciation of all aspects of the manoeuvrability vessel handling turning characteristics outboard engines etc the Contractor shall provide an appropriate training course for 6 officers of the HPS upon the Delivery Acceptance An operation training programme shall be proposed for the consideration by GNC and HPS which shall include details of depth and duration of the training course The training instructors have suitable qualifications acceptable to MD A certificate shall also be issued to the trainees upon completion of the training course 39 3 The engineering work up team and front line maintenance teams of the maintenance personnel of the Government Dockyard acquire full knowledge and appreciation of all aspects of the designs day to day operation breakdown routine maintenance and fault diagnosis of the outboard engine elec
129. ropriate earthing connection shall be provided for protecting the radio equipment All outdoor connector joint shall be properly covered by waterproof tape or material a One Radar Reflector shall be provided 36 11 Installation Requirements a General Requirements 36 1 1 a 1 36 1 1 a 2 36 11 a 3 Part VII Technical Specification Page 30 of 37 In addition to the following requirement the work under this Contract shall also comply with EMSD General Requirements for Electronic Contract ESGOlat http www emsd gov hk emsd e_download about tcs pdf esg01 pdf where applicable The control panel of all equipment shall be installed and flush mounted in the coxswain operation area unless otherwise specified The mounting screw shall be detachable from the front of the equipment and the equipment shall be taken out at the front for further checking or replacement The Contractor shall submit a layout plan showing the exact locations of the equipment Equipment supplied complete with all standard and or maker recommended accessories as required for normal operation Supply of Two Units of Speed Boats for Marine Department Tender Ref Marine Department Shipbuilding Tender No 3 2015 36 11 a 4 The equipment supplied shall complete with all the auxiliary items required for normal operation including connectors circuit breakers power sockets interface device plugs and cables with conduits Additional power conditioners filterin
130. rs USD 177 reduced by 10 New Jersey for stay in any one Trenton USD 242 city Atlantic City USD 200 Others USD 242 New Mexico Santa Fe USD 205 Others USD 205 New York State Albany USD 220 Ithaca USD 210 New York USD 447 Others USD 220 North Carolina Raleigh USD 206 Charlotte USD 208 Others USD 206 North Dakota Bismarck USD 165 Others USD 165 Northern Mariana Islands Saipan USD 296 Others USD 296 Ohio Columbus USD 207 Others USD 207 Oklahoma Oklahoma City USD 200 Others USD 200 Oregon Salem USD 165 41 Amendment No 8 41 2015 Tender Ref Marine Department Shipbuilding Tender No 3 2015 Annex 4 10 First 28 nights Thereafter Country Currency City Portland USD 262 Others USD 165 All rates to be Pennsylvania reduced by 10 Harrisburg USD 205 for stay in any one Philadelphia USD 290 city Pittsburgh USD 254 Others USD 205 Puerto Rico San Juan USD 407 Others USD 407 Rhode Island Providence USD 258 Others USD 258 South Carolina Columbia USD 185 Others USD 185 South Dakota Pierre USD 165 Others USD 165 Tennessee Nashville USD 253 Others USD 253 Texas Austin USD 257 Dallas USD 254 Houston USD 254 San Antonio USD 230 Others USD 257 Utah Salt Lake City USD 217 Others USD 217 Vermont Montpelier USD 218 Others USD 218 42 Amendment No 8 42 2015 Tender Ref Marine Department Shipbuilding Tender No 3 2015 Annex 4 10 First 28 nights Thereafter
131. rs should be assumed to be congregated at 0 25 square metre per person on the uppermost deck s with two thirds of the passengers distributed on one side of the vessel and one third on the other side The vertical centre of gravity of each person should be taken as a standing passenger Turning moment of vessel the heeling moment developed due to the effect of turning the vessel should be calculated by the following formula Where Me heeling moment in tonne metres Mr 0 02 Vo Dr KG d 2 Lw Vo service speed in metre second Dr displacement in tonnes KG height of centre of gravity from keel in metres d mean draught in metres Lw length of vessel at waterline in metres Damaged Stability Criteria Transverse bulkheads shall be arranged to sustain flooding of any one full compartment and asymmetric flooding due to damage of any smaller watertight compartment within full compartment The residual stability shall be sufficient to maintain the vessel survive in case of damage N B Part VII Technical Specifications Annex 2 Stability Requirement The Contractor should note that the opening to be used to determine the down flooding angle is to be agreed with MD Supply of Two 2 Speedboats for MD Page 2 of 2 Tender Ref Marine Department Shipbuilding Tender No 3 2015 Part VII Annex 3 Guidance General Arrangement Plan EN Cq c Part VII Technical Specifications Annex 3
132. s PKR 22 237 Palau Koror USD 287 Others USD 287 Panama Panama City PAB 254 Colon PAB 254 David Chiriqui PAB 195 Others PAB 142 Papua New Guinea Port Moresby PGK 1 254 Others PGK 804 Paraguay Asuncion PYG 1 215 104 Ciudad del Este PYG 977 464 Pegro Juan PYG 542 537 Others PYG 547 021 28 Amendment No 8 28 2015 Tender Ref Marine Department Shipbuilding Tender No 3 2015 Annex 4 10 First 28 nights Thereafter Country Currency City Peru Lima PEN 980 All rates to be Cusco PEN 963 reduced by 10 Paracas PEN 792 for stay in any one Others PEN 569 city Philippines Manila PHP 10 638 Cebu PHP 8 170 Davao City PHP 6 823 Others PHP 8 439 Poland Warsaw PLN 911 Gdansk PLN 832 Katowice PLN 1 027 Krakow PLN 1 179 Poznan PLN 1 063 Wroclaw PLN 812 Zakopane PLN 729 Others PLN 812 Portugal Lisbon EUR 210 Cascais EUR 183 Estoril EUR 183 Faial Island EUR 157 Madeira Islands EUR 156 Oeiras EUR 183 Oporto EUR 172 Ponta Delgada EUR 203 Sao Miguel Island EUR 203 Others EUR 148 Qatar Doha QAR 1 242 Others QAR 1 242 29 Amendment No 8 29 2015 Tender Ref Marine Department Shipbuilding Tender No 3 2015 Annex 4 10 First 28 nights Thereafter Country Currency City Republic of the Congo Brazzaville XAF 184 688 All rates to be Others XAF 184 688 reduced by 10 Reunion for stay in any one Reunion EUR 175 city Romania Bucharest RON 892 Constanta RON 626 Others RON
133. s CHF 445 Geneva CHF 475 Klosters CHF 447 Lugano CHEF 422 Montreux CHF 484 33 Amendment No 8 33 2015 Tender Ref Marine Department Shipbuilding Tender No 3 2015 Annez 4 10 First 28 nights Thereafter Country Currency City Zurich CHF 440 Others CHF 381 All rates to be Syria reduced by 10 Damascus SYP 55 642 for stay in any one Others SYP 55 642 city Tajikistan Dushanbe TJS 1 625 Khorog TJS 1 280 Kulob TJS 775 Others TJS 775 Tanzania Dar Es Salaam TZS 517 757 Arusha TZS 402 142 Morogoro TZS 330 091 Zanzibar TZS 480 894 Others TZS 263 068 Thailand Bangkok THB 8 826 Chiang Mai THB 6 879 Chiang Rai THB 4 218 Hat Yai THB 4 218 Hua Hin THB 7 204 Khao Lak THB 9 118 Krabi THB 9 118 Nong Khai THB 3 440 Pattaya City THB 6 263 Phuket THB 9 118 Samui Island THB 7 528 Others THB 3 440 The Gambia Banjul GMD 8 433 Others GMD 2 653 34 Amendment No 8 34 2015 Tender Ref Marine Department Shipbuilding Tender No 3 2015 Annex 4 10 First 28 nights Thereafter Country Currency City Timor Leste Dili USD 221 All rates to be Others USD 100 reduced by 10 Togo for stay in any one Lome XOF 138 389 city Lama Kara XOF 56 708 Sokode XOF 57 229 Others XOF 44 222 Tokelau Islands Tokelau Islands NZD 49 Tonga Nukualofa TOP 511 Others TOP 511 Trinidad and Tobago Port of Spain TTD 2 216 Tobago TTD 2 565 Others TTD 2 216 Tunisia Tunis TND 390 Carthage TND 390 Gamm
134. s MVR 6 752 Mali Bamako XOF 135 788 Others XOF 65 553 Malta Malta EUR 211 Marshall Islands Majuro USD 215 Kwajalein Atoll USD 176 Likiep Atoll USD 113 Others USD 83 Martinique Martinique EUR 282 Mauritania Nouakchott MRO 63 904 Kaedi MRO 25 970 Nouadhibou MRO 38 518 Others MRO 26 554 Mauritius Mauritius MUR 7 453 Mayotte Islands Mayotte Islands EUR 163 Mezico Mezico City D F MXN 4 866 Acapulco MXN 3 522 Cabo San Lucas MXN 5 122 Campeche MXN 2 568 Cancun MXN 4 853 23 Amendment No 8 23 2015 Tender Ref Marine Department Shipbuilding Tender No 3 2015 Annex 4 10 First 28 nights Thereafter Country Currency City Chihuahua MXN 2 554 Ciudad Juarez MXN 1 895 All rates to be Ciudad Victoria MXN 2 030 reduced by 10 Colima MXN 2 621 for stay in any one Cozumel MXN 3 092 city Cuernavaca MXN 2 836 Culiacan MXN 1 707 Ensenada MXN 2 823 Guadalajara MXN 3 226 Hermosillo MXN 2 339 Huatulco MXN 2 890 Ixtapa Zihuatanejo MXN 2 514 La Paz MXN 2 541 Manzanillo MXN 3 078 Matamoros MXN 2 030 Mazatlan MXN 2 500 Merida MXN 2 890 Mexicali MXN 2 984 Monterrey MXN 3 455 Morelia MXN 2 312 Nogales MXN 2 594 Nuevo Laredo MXN 2 151 Playa del Carmen Quintana Roo MXN 3 078 Puebla MXN 2 662 Puerto Penasco MXN 2 756 Puerto Vallarta MXN 3 764 Queretaro MXN 2 312 San Carlos MXN 2 178 San Miguel de Allende MXN 2 406 Tapachula MXN 2 030 Tijuana MXN 2 742 Valle del Bravo MXN 4 530 Veracruz MXN 2 568 24 Amendmen
135. s as stated in Clause 2 1 6 to this Part All the fittings hoses and piping shall withstand the system test pressure without leaks 25 Fuel System and fuel oil Tank 25 1 Fuel System 25 1 1 Individual components of the system and the system as a whole shall be designed to withstand the combined conditions of pressure vibration shocks corrosion and movement encountered under normal operating conditions and storage 25 1 2 Each component of the system and the system as a whole shall be capable of operation within Part VII Technical Specification Page 15 of 37 Supply of Two Units of Speed Boats for Marine Department Tender Ref Marine Department Shipbuilding Tender No 3 2015 an ambient temperature range of 10 C to 82 C without failure or leakage and be capable of being stored without operation within an ambient temperature range of 30 C to 80 C without failure or leakage 25 1 3 All materials used in fuel systems shall be resistant to deterioration by its designated fuel and to other liquids or compounds with which it may come into contact under normal operating conditions e g grease lubricating oil bilge solvents and sea water 25 1 4 No electrical component device cable shall run through or installed inside the petrol tank compartment otherwise the electrical component device cable located in compartment shall be ignition protected so that 25 1 4 1 It will not ignite a flammable hydrocarbon mixture surr
136. s shall be designed or installed so that no exterior surface will trap water 25 2 6 11 Tank drains are not permitted on petrol fuel tanks 25 3 Diesel Tank 25 3 1 25 3 2 25 3 3 25 3 4 29 39 25 3 6 One marine grade stainless steel 316 diseel tanks shall be mounted at under deck position The tanks shall not be integral with the hull and shall be installed so that the loads due to the mass of the full tank are safely induced into the structure with due consideration given to upward and downward acceleration due to the vessel s movements at maximum speed in the sea In this respect continuous flexible supports spreading loads are preferable to rigid ones The design and tests shall comply with the requirements of Recognised Organisation or other international standards acceptable to MD Except the electric wires for the fuel oil tank level sensor s no other should pass through any fuel tank compartment s Ventilation for the fuel tank compartment s shall comply with national or other acceptable industrial standards The total capacity of the tank shall be provide fuel supplied to electrical generator maintain full load operation for 72 hours The unpumpable capacity of the each tank shall not be more than 10 of the capacity of that tank It is preferable to have both of the tanks containing the same capacity of petrol All seals such as gaskets O rings and joint rings shall be of non wicking i e non fuel absorbent
137. s shall be in compliance with the International Regulations for Preventing Collisions at Sea 1972 as amended by IMO Resolution A 464 XID and A 626 XV with certificate by HKMD recognised classifications 31 1 2 The lights shall be controlled from the control and alarm panel at the control console Each navigation light circuit shall be provided with a switch protection fuse indicating lamp and alarm Dimmer for the Part VII Technical Specification Page 21 of 37 Supply of Two Units of Speed Boats for Marine Department Tender Ref Marine Department Shipbuilding Tender No 3 2015 panel indication lights buzzer stop and lamp test buttons shall be fitted 31 1 3 Navigation light circuits shall be independent of any other electrical circuits There shall be two essentially separate power supply systems to the distribution board 31 1 4 The following navigation lights shall be provided together with protection system as stated at a Port side light b Starboard side light c Stern light d Masthead light and e Anchor light 31 2 The following signalling equipment shall be provided 31 2 1 One all round red flashing light 31 2 2 One siren 31 2 3 COLREG Rule 27e i Three all round lights in vertical Line Red White Red 31 24 Three black ball 31 2 5 One black diamond and 31 2 6 One bell 0 2 m mouth diameter 31 3 One set of spare navigation light and two sets of light bulb for all light signal shall be provided whe
138. shall be prepared in a format agreed by GNC 6 4 Official Speed Trial 6 4 1 As part of the Technical Acceptance as specified in paragraph 4 2 of this Chapter 1 the Contractor shall carry out an official speed trial Official Speed Trial in the presence of GNC officers or their appointed agents or MD authorized representatives Of the essence the Vessel shall achieve the Contract Speed 6 4 2 The actual mean speed of the Vessel i e NOT theoretical shall be measured during the Official Speed Trial runs to determine if the Contract Speed can be achieved The speed calculations must NOT be corrected by wind wave tidal current shallow water effects and weather condition 6 4 3 The mean speed is to be calculated as the arithmetic mean of not less than FOUR continuous runs i e TWO runs in each direction The speed for each run shall be taken by measuring the time of the vessel running for one nautical mile between two poles or other measuring method acceptable to MD 6 4 4 The Contract Speed is considered not achieved if the Contract Speed cannot be obtained during the Official Speed Trial after a total of FIVE runs in each direction 6 4 5 The Contract Speed to be achieved by the Vessel in the Official Speed Trial shall be the minimum highest achievable speed of 35 knots and the Vessel under the official speed trial conditions as stated in Annex 8 to this Part If the Vessel fails to achieve the minimum highest achievable speed under the a
139. shipboard services Batteries shall be permanently installed in a dry ventilated location above the anticipated bilge water level Batteries shall be installed in a manner to restrict their movement horizontally and vertically considering the intended use of the Vessel A battery as installed shall not move more than 10 mm in any direction when exposed to a force corresponding to twice the battery weight Batteries shall be installed designed or protected so that metallic objects cannot come into unintentional contact with any battery terminal Batteries as installed shall be protected against mechanical damage at their location or within their enclosure Batteries shall not be installed directly above or below a fuel tank or fuel filter Any metallic component of the fuel system within 300 mm above the battery top as installed shall be electrically insulated Battery cable terminals shall not depend on spring tension for mechanical connection to them A battery disconnect switch shall be installed in the positive conductor from the battery or group of batteries connected to the supply system voltage in a readily accessible location as close as practical to the battery or group of batteries except the circuits for engine starting and navigation lighting and electronic devices with protected memory and protective devices such as bilge pumps and Part VII Technical Specification Page 19 of 37 Supply of Two Units of Speed Boats for Mar
140. t No 8 24 2015 Tender Ref Marine Department Shipbuilding Tender No 3 2015 Annex 4 10 First 28 nights Thereafter Country Currency City Zacatecas MXN 2 648 Others MXN 2 245 All rates to be Micronesia reduced by 10 Pohnpei USD 201 for stay in any one Chuuk USD 185 city Kosrae USD 198 Yap USD 198 Others USD 185 Moldova Chisinau MDL 3 413 Others MDL 3 413 Monaco Monaco EUR 496 Mongolia Ulaanbaatar MNT 523 688 Others MNT 295 838 Montenegro Podgorica EUR 250 Others EUR 250 Montserrat Montserrat XCD 381 Morocco Rabat MAD 2 299 Agadir MAD 2 053 Casablanca MAD 2 790 Fes MAD 3 010 Marrakech MAD 2 790 Tangier MAD 2 439 Taroudant MAD 2 202 Others MAD 2 001 Mozambique Maputo MZN 8 823 Pemba MZN 9 348 Others MZN 9 348 25 Amendment No 8 25 2015 Tender Ref Marine Department Shipbuilding Tender No 3 2015 Annex 4 10 First 28 nights Thereafter Country Currency City Namibia Windhoek NAD 2 731 All rates to be Etosha NAD 1 738 reduced by 10 Swakopmund NAD 2 268 for stay in any one Walvis Bay NAD 1 873 city Others NAD 1 659 Nauru Nauru AUD 286 Nepal Kathmandu NPR 25 344 Pokhara NPR 18 145 Others NPR 18 540 Netherlands The Hague EUR 282 Amsterdam EUR 341 Coevorden EUR 249 Eindhoven EUR 291 Lisse EUR 271 Maastricht EUR 338 Noordwijk EUR 269 Papendrecht EUR 290 Rotterdam EUR 290 Schiphol EUR 291 Utrecht EUR 255 Ypenburg EUR 282 Others EUR 274 Netherlands A
141. t air Ripples without crests direction Leaves and wind 13 knot 0 1 ft vanes are stationary 0 3 1 5 m s 5 6 11 km h 2 3 m s re 2 0 5 m 4 7 mph Small wavelets Crests of glassy Mandie on exposed skani 2 Light breeze Leaves rustle Wind vanes 4 6 knot appearance not breaking begini to tove 1 2 ft i 1 6 3 4 m s 12 19 km h 3 5 m s 0 3 1 m Leaves and small twigs Gentle 8 12 mph Large wavelets Crests begin to 3 constantly moving light flags breeze 7 10 knot break scattered whitecaps tended 2 3 5 ft 3 5 5 4 m s 20 28 km h 6 8 m s E m i Moderate 13 17 mph Small waves with breaking crests Pust and loose paper pales 4 Small branches begin to breeze 11 16 knot Fairly frequent whitecaps Rove 3 5 6 ft i 5 5 7 9 m s 29 38 km h 8 1 10 6 m s Fresh 18 24 mph oom Moderate waves of some length Branches of a moderate size 5 aes Many whitecaps Small amounts of move Small trees in leaf 17 21 knot 6 9 ft spray begin to sway 8 0 10 7 m s 39 49 km h 10 8 13 6 m s 34m Large branches in motion 25 30 mph Long waves begin to form White Whistling heard in overhead Strong p 6 Breeze foam crests are very freguent wires Umbrella use becomes 22 27 knot 9 13 ft Some airborne spray is present difficult Empty plastic bins 10 8 13 8 m s tip over Hish wind 50 61 km h 13 9 16 9 m s 45 5 m Sea heaps up Some foam from 8 A breaking waves is blown into Whole trees in motion Effort moderate 31 38 mph tee 7 ale strea
142. te notice as aforesaid 5 4 1 An Implementation Timetable in the form set out in Annex 4 to this Part setting out the major milestones and their scheduled completion dates and incorporating the Delivery Dates specified in Schedule 2 and 5 4 2 The Timetable for Major Items Inspection in the form set out in Annex 6 to this Part and 5 4 3 The Timetable for submission of Drawing in the form set out in Annex 5 to this Part shall each be submitted to GNC for approval by the respective deadlines specified in Clause 11 of the Conditions of Contract The Delivery Date s for the Vessel as stated in the Implementation Timetable shall be no later than those set out in Schedule 2 The completion dates for the milestones as specified in the Implementation Timetable in the form set out in Annex 4 and any other milestones which the Contractor consider necessary shall be completed by the Contractor and subject to GNC s acceptance The Implementation Timetable shall also be consistent with the summary table of survey visits set out in Schedule 10 and the two timetables mentioned in 5 4 2 and 5 4 3 of this paragraph The Government may suspend payment if any of the timetables required herein has not been submitted for GNC s acceptance or GNC does not accept any of them or if the progress of work does not comply with any of them as approved by the GNC 5 5 A monthly work progress report with photos evidencing the progress is required to be submitted to MD duri
143. thers 9 Documentation 9 1 Final As Built Drawings Details of the documents submission have to be discussed in the Kick Off Meeting 9 2 Equipment Manuals 9 3 Sea Trial Reports Part VII Technical Specifications Annex 6 Main Inspection Items Supply of Two Units of Speed Boats for Marine Department Page 3 of 3 Tender Ref Marine Department Shipbuilding Tender No 3 2015 Part VII Annex 7 List of Government Dockyard Contractors Item III Hull Deck amp Tailshaft Group II Name of Contractor amp Address Cheoy Lee Shipyards Ltd 89 amp 91 Hing Wah Street West Lai Chi Kok Kowloon Hong Kong Chu Kong Group Shipyard Co Ltd Chu Kong Group Shipyard Building 93 Hing Wah Street West Lai Chi Kok Kowloon Hong Kong Telephone No 852 2307 6333 852 2815 0333 852 2987 7351 Fax No 852 2307 5577 852 2815 2188 Contact Person C Y Cheung Chan Wai Mui Discovery Bay Enterprises Ltd 852 2987 3915 852 2987 5246 Unit 101 Discovery Bay Office Centre No 2 Chan Kam Bue Plaza Lane Discovery Bay Lantau Island Hong Kong ka RS 83224353327 Fat Kee Marine Repairing amp Engineering Co Ltd 852 2435 2435 852 2768 8811 Siu Chan Shing P O BOX 78638 Mongkok Post Office Kowloon Hong Kong 852 9224 0044 852 2435 3344 Hongkong United Dockyards Ltd TYTL 108 RP Sai Tso Wan Road Tsing Yi Island N T Hong Kong 852 2431 260
144. to complete the work required in this chapter An integrated system is required so that information and also the display monitors of different systems such as radar system compass could be shared in order to utilize the limited space available in coxswain operation area and to provide users a better displaying interface The Contractor shall refer to Appendix A in this chapter for the conceptual block diagram of electronic equipment for this vessel All equipment offered shall be designed for marine applications and shall allow effective operation under most arduous condition i e severe vibration poor weather strong winds and heavy rains etc Exposed components shall be of weather proof and adequate protection against splash and water shall be provided for all electronic equipment fitted on board All components of the equipment exposed to the weather shall be sea water resistance Internal components shall be fully enclosed with heavy duty seals and sufficient heat dissipation mechanism e g ventilation conduction etc to protect the equipment The Contractor shall pay attention to the Compass Safe Distance of the equipment and the Radiation Hazard Zone of the radar scanner in the vessel design All radar and radio equipment shall be type approved by the Office of Communication Authority of Hong Kong All sitting installation and cabling in respect of compass VHF radar etc shall comply with the relevant rules and regulations of H
145. to this part 6 6 Manoeuvrability Test Part VII Technical Specification Page 7 of 37 Supply of Two Units of Speed Boats for Marine Department Tender Ref Marine Department Shipbuilding Tender No 3 2015 6 6 1 Maximal manoeuvring speed to be achieved by the Vessel in the Manoeuvrability Test shall not be less than 35 knots 6 6 2 Forward Turning Circle tests to port and starboard sides with both engines and single engine running shall be conducted The minimum time for turning to both sides at 15 90 180 270 and 360 shall be recorded 6 6 3 The results for above two tests shall form part of Sea Trial Report that shall be submitted to GNC before Delivery Acceptance 6 7 Crash Stop Test The minimum time and distance from full ahead to stop and to full astern shall be determined at the Crash Stop Test The minimum time and distance requirements are set out in Annex 8 The testing results shall be recorded and form part of Sea Trial Report that shall be submitted to GNC before Delivery Acceptance 6 8 Astern Running Test Emergency Steering Test The astern running and the emergency steering operation shall be recorded and form part of Sea Trial Report that shall be submitted to GNC before Delivery Acceptance The conditions of the tests are set out in Annex 8 6 9 The following tests shall be conducted and the testing results shall be recorded and form part of Sea Trial Report that shall be submitted to GNC before Delivery Accept
146. trical distribution system hull structural repair etc The Contractor shall therefore provide appropriate train the trainer courses for a total of 10 maintenance personnel from the Government Dockyard respectively in the HKSAR or overseas after the delivery of the Vessel to the Government Dockyard A certificate shall also be issued to the trainees upon completion of the training course 394 All of the above mentioned training courses and the facilities venue and materials necessary for the above mentioned training courses and otherwise required in these Technical Specifications shall be provided by the Contractor at no charge to the Government unless otherwise specified The training shall also be conducted in Chinese and English with relevant training materials to be supplied by the Contractor The training materials shall be provided before the training in both paper and CD ROM format Part VII Technical Specification Page 37 of 37 Supply of Two Units of Speed Boats for Marine Department Tender Ref Marine Department Shipbuilding Tender No 3 2015 Part VII Annex 1 Warranty Services and Guarantee Slipping Warranty Services 1 1 1 3 1 4 1 5 1 6 The Contractor is required to be a Government Recognised Servicing Shipyard GRSS or appoints a GRSS in Hong Kong for providing Warranty Services in relation to all aspects of the Vessel during the Warranty Period including Guarantee Slipping as stipulated in this Annex
147. ts of that equipment or installation in the Warranty Period applicable to such items During the Warranty Period when the Vessel is handed over to the GRSS for the Warranty Services and or Guarantee Slipping the Contractor shall be responsible for the due return of the Vessel in good order Should there be any loss or damage of the Vessel or any Warranty Item as defined in paragraph 1 5 below caused by any reason whatsoever while the Vessel is in the possession or control of the Contractor including even when the Vessel is at the Government Dockyard or a maintenance base of the user department or at the shipyard of the Contractor or the GRSS appointed by it the Contractor shall pay for the cost for the loss or damage plus 20 as and for liquidated damages but not as a penalty Throughout the Warranty Period notwithstanding anything to the contrary in the Contract the Vessel and all Warranty Items are deemed to be at the Contractor s risks and the Contractor shall insure and keep insured at his own expense a property insurance with the Government to be named as the sole payee for an indemnity amount of not less than the purchase price of the Vessel plus 20 to protect the Government property against all risks Certificate of Insurance and evidence showing premium being paid shall be available for inspection in advance The Contractor provides this insurance policy before the signing of Contract Any excess payable under the insurance policy shal
148. ty Solomon Islands Solomon Islands SBD 2 275 All rates to be Somalia reduced by 10 Mogadishu SOS 161 338 for stay in any one Others SOS 131 087 city South Africa Pretoria ZAR 3 024 Bloemfontein ZAR 2 076 Cape Town ZAR 3 995 Durban ZAR 3 205 Johannesburg ZAR 3 961 Sun City ZAR 2 923 Others ZAR 2 257 South Sudan Juba SDG 1 549 Others SDG 1 549 Spain Madrid EUR 321 Almeria EUR 244 Balearic Islands EUR 280 Barcelona EUR 324 Bilbao EUR 211 Fuengirola EUR 217 La Coruna EUR 212 Las Palmas de Gran Canaria EUR 253 Malaga EUR 219 Marbella EUR 219 Oviedo EUR 189 San Sebastian EUR 201 Santa Cruz de Tenerife EUR 193 Santander EUR 229 Santiago de Compostela EUR 239 Seville EUR 224 Valencia EUR 204 32 Amendment No 8 32 2015 Tender Ref Marine Department Shipbuilding Tender No 3 2015 Annex 4 10 First 28 nights Thereafter Country Currency City Vigo EUR 207 Zaragoza EUR 300 All rates to be Others EUR 222 reduced by 10 Sri Lanka for stay in any one Colombo LKR 43 063 city Ahungalla LKR 21 923 Bentota LKR 19 052 Chilaw LKR 19 704 Galle LKR 28 186 Kandy LKR 32 101 Trincomalee LKR 30 144 Others LKR 19 835 St Lucia Saint Lucia XCD 970 Sudan Khartoum SDG 2 761 Others SDG 2 289 Suriname Paramaribo SRD 612 Others SRD 612 Swaziland Mbabane SZL 2 212 Others SZL 982 Sweden Stockholm SEK 3 110 Others SEK 3 110 Switzerland Bern CHF 440 Basel CHF 414 Davo
149. ufactured to at least the standards as specified in these Technical Specifications For items which are not specified above then to at least to one of those standards prescribed by or recommended by the following organizations BSI British Standards Institute Part VII Technical Specification Page 9 of 37 Supply of Two Units of Speed Boats for Marine Department Tender Ref Marine Department Shipbuilding Tender No 3 2015 DIN Deutsche Industrie Normen FEM Federation Europeenne de la Manutention GB Chinese Standard Institute TEEE Institute of Electrical and Electronic Engineers ISO International Standards Organisation JIS Japanese Industrial Standards 2 2 The Contractor shall note that although the Vessel is to be built to international Classification rules the Vessel shall not be classed The interpretation of the rules shall normally follow past and common practice Nevertheless the final interpretation of rules shall rest with MD 2 3 Quality and standards of construction not mentioned in this specification shall comply with the relevant international standards or rules 24 The Contractor shall be required to submit a full list of applicable rules regulations and standards to which the proposed Vessel complies during the design stage of the Vessel 3 Shipyard 3 1 The Tenderer s shipyard design office shall be headed by a ship designer with professional qualification in ship design and construction such as corporate member of
150. uirement c The course shall be held immediately before the Delivery Acceptance of the Vessel d A total of up to 22 trainees will attend the course The training course shall accommodate the specified number of trainees 36 14 3 Equipment Maintenance Training Course a The Contractor shall provide full training facilities e g accommodation facilities and equipment with a training schedule The course is to give the maintenance staff to acquire a full knowledge and appreciation of all aspects on the design considerations day to day operation inter connected system operation fault breakdown routine maintenance and fault finding repairing procedures of all ENE specified in this paragraph 36 This shall include practical demonstrations and tests b The maintenance training shall include but not limited to the following items a Introduction of the equipment locations b Equipment operational working principle and functional descriptions c Equipment block and schematic functional descriptions d Equipment adjustment calibration procedure and parameter settings e Equipment construction and mounting f Equipment interfacing and signal interfacing g Preventive maintenance and trouble shooting c This shall enable technical staff to effectively maintain the equipment d Thecourse shall be held immediately after the Delivery Acceptance of the Vessel e A total of up to 15 trainees will attend the course The t
151. ural Construction and Hull Scantlings drawings 1 2 11 Hull Shell and Frames and the Framings Arrangement and Construction Plan 1 2 12 Hull Shell Expansion Plan 1 2 13 Keel Construction plan 1 2 14 Steering system and steering arrangement diagrams 1 2 15 Superstructures and Deck Structural and Construction Plan 1 2 16 Hull Watertight Bulkheads Construction Plan 1 2 17 Superstructures to deck connection detailed construction plan 1 2 18 Deck Edge and Bulwark if any details and construction plan including detailed structural arrangement drawings of hull to deck connection 1 2 19 Detailed Cathodic corrosion prevention and arrangement plans and drawings for the Vessel throughout 1 2 20 Mast structural and construction Plan and Mast Equipment Arrangement Plan Part VII Technical Specifications Annex 14 Page 1 of 2 Supply of Two Units of Speed Boats for Marine Department Tender Ref Marine Department Shipbuilding Tender No 3 2015 1 2 21 1 2 22 1 2 23 1 2 24 1 2 25 1 2 26 1 2 27 1 2 28 1 2 29 1 2 30 1 2 31 1 2 32 1 2 33 1 2 34 1 2 35 1 2 36 1 2 37 1 2 38 1 2 39 Anchoring Arrangement Plan Piping diagrams for fuel oil freshwater lubrication oil bilge firefighting scuppers and drains sewage system Fire Prevention Fire Control and Firefighting System drawings Drawings of the main switchboard and all other switchboards and the electrical system wheelhouse and
152. uzhou RMB 1 834 Guangzhou RMB 2 505 Guilin RMB 1 649 Haikou RMB 1 902 Hangzhou RMB 1 619 Harbin RMB 1 772 Jinan RMB 1 268 Lhasa RMB 1 126 Lijiang RMB 886 Nanjing RMB 1 379 Nanning RMB 1 539 Ningbo RMB 1 514 Qingdao RMB 1 508 Sanya RMB 1 717 Shanghai RMB 2 031 Shantou RMB 1 397 Shenyang RMB 1 846 7 Amendment No 8 7 2015 Tender Ref Marine Department Shipbuilding Tender No 3 2015 Annez 4 10 First 28 nights Thereafter Country Currency City Shenzhen RMB 2 456 Suzhou RMB 1 668 All rates to be Tianjin RMB 1 495 reduced by 10 Urumqi RMB 1 385 for stay in any one Wuhan RMB 1 662 city Xiamen RMB 1 668 Xian RMB 1 557 Zhuhai RMB 1 637 Others RMB 1 662 Hong Kong Hong Kong HKD 2 700 Macau Macau MOP 3 524 Taiwan Taipei NTD 8 526 Kaohsiung NTD 5 968 Taichung NTD 5 755 Others NTD 5 846 Cocos Keeling Islands Cocos Islands AUD 124 Colombia Bogota COP 773 019 Barranguilla COP 453 289 Buenaventura COP 443 171 Cali COP 503 879 Cartagena COP 831 704 Medellin COP 530 186 San Andres COP 505 903 Santa Marta COP 503 879 Others COP 505 903 Comoros Moroni KMF 147 080 Others KMF 68 273 Amendment No 8 8 2015 Tender Ref Marine Department Shipbuilding Tender No 3 2015 Annex 4 10 First 28 nights Thereafter Country Currency City Cook Islands Rarotonga NZD 487 All rates to be Others NZD 487 reduced by 10 Costa Rica for stay in any one San Jose CRC 137 917 city Others CRC 137 917
153. vailable 29 6 4 3 Indication light for Shore Power Breaker Opened and 29 6 4 4 Indication light for Shore Power Breaker Closed 29 6 5 Shore Power Connection Box 29 6 5 1 Not less than 15 meters long shore connection power cable of adequate rating with quick release watertight plug shall be provided 29 6 5 2 The connection box must be of watertight design with quick release receptacle for marine application Receptacles Sockets 29 7 1 Receptacles sockets installed in locations subject to rain spray or splashing shall have a minimum protection of IP55 in accordance with IEC60529 when not in use e g protected by a cover with an effective weatherproof seal Lighting 29 8 1 All lightings shall be equipped with LED bulbs including the navigation lights Ignition Protection 29 9 1 Compartments which may contain explosive gases are those containing or which have open connections with compartments containing such items as 29 9 1 1 Fuel tank Compartment 29 9 1 2 Joints or fittings in fuel lines connecting spark ignition engines with their fuel tanks 30 Bilge System 30 1 30 2 30 3 Vessel shall be designed and constructed so as to prevent the accidental discharge of pollutants oil fuel overboard Electrical bilge pump shall be provided at the stern Manual bilge pump shall be provided at the stern for all separate compartments 31 Navigational And Signalling Equipment 31 1 NavigationLights 31 1 1 Navigation light
154. y The engines shall be designed to trim fully in to start and trimmed out as the boat gains momentum until it reaches the point just before ventilation begins 21 8 The engine located at the transom shall be easily accessed for maintenance and routine checking even underway A working platforms for engine maintenance purpose shall be fitted 21 9 The electrical cables pipings for petrol and hydraulic oil run between the console fuel tanks and the stern shall be suitably designed to ease the maintenance They shall be properly supported to prevent chafing and unnecessary tension 21 10 Each engine system shall include the following accessories Part VII Technical Specification Page 14 of 37 Supply of Two Units of Speed Boats for Marine Department Tender Ref Marine Department Shipbuilding Tender No 3 2015 21 10 1 24V or 12V electrical system c w alternator and remote starting control 21 10 2 Dead manswitch emergency cut off 21 10 3 Power trim and tilt system with trim gauge at console 21 10 4 Engine protection system as required by engine manufacturer with audio and visual warnings at console 21 10 5 Each engine shall incorporate one alternator for battery charging 21 10 6 Engine tie bar with each pair of engines 22 Engine Installation 22 1 The main and auxiliary engines shall be installed in accordance with the engine maker s instructions and requirements The Contractor shall submit a certificate report issued by the e

Technical Specifications with annexes

Contents

Download Pdf Manuals

Related Search

Related Contents